11210. This chapter may be cited as the Vacation Ownership and Time-share Act of 2004.

11211. The purposes of this chapter are to do all of the following:

(a) Provide full and fair disclosure to the purchasers and prospective purchasers of time-share plans.

(b) Require certain time-share plans offered for sale or created and existing in this state to be subject to the provisions of this chapter.

(c) Recognize that the tourism industry in this state is a vital part of the state's economy; that the sale, promotion, and use of time-share plans is an emerging, distinct segment of the tourism industry; that this segment of the tourism industry continues to grow, both in volume of sales and in complexity and variety of product structures; and that a uniform and consistent method of regulation is necessary in order to safeguard California's tourism industry and the state's economic well-being.

(d) In order to protect the quality of California time-share plans and the consumers who purchase them, it is the intent of the Legislature that this chapter be interpreted broadly in order to encompass all forms of time-share plans with a duration of at least three years that are created with respect to accommodations that are located in the state or that are offered for sale in the state, including, but not limited to, condominiums, cooperatives, vacation clubs, and multisite vacation plans.

(e) It is the intent of the Legislature that this chapter not be interpreted to preempt the application of, the enforcement of, or alter the standards of, the general consumer protection laws of this state set forth in Sections 17200 to 17209, inclusive, and Sections 17500 to 17539.1, inclusive, of the Business and Professions Code.

11211.5. (a) This chapter applies to all of the following:

(1) Time-share plans with an accommodation or component site in this state.

(2) Time-share plans without an accommodation or component site in this state, if those time-share plans are sold or offered to be sold to any individual located within this state.

(3) Exchange programs as defined in this chapter.

(4) Short-term products as defined in this chapter.

(b) This chapter does not apply to any of the following:

(1) Time-share plans, whether or not an accommodation is located in this state, consisting of 10 or fewer time-share interests. Use of an exchange program by owners of time-share interests to secure access to other accommodations shall not affect this exemption.

(2) Time-share plans, whether or not an accommodation is located in this state, the use of which extends over any period of three years or less.

(3) Time-share plans, whether or not an accommodation is located in this state, under which the prospective purchaser's total financial obligation will be equal to or less than three thousand dollars ($3,000) during the entire term of the time-share plan.

(c) For purposes of determining the term of a time-share plan, the period of any renewal or renewal option shall be included.

(d) Single site time-share plans located outside the state and component sites of multisite time-share plans located outside the state, that are offered for sale or sold in this state are subject only to Sections 11210 to 11219, inclusive, Sections 11225 to 11245, inclusive, Sections 11250 to 11256, inclusive, paragraphs (1), (2), (3), and (4) of subdivision (a), and subdivisions (b) and (c), of Section 11265, subdivision (g) of Section 11266, subdivisions (a) and (c) of Section 11267, Sections 11272 and 11273, subdivisions (b), (c), and (d) of Section 11274, and Sections 11280 to 11287, inclusive.

11211.7. (a) Any time-share plan registered pursuant to this chapter to which the Davis-Stirling Common Interest Development Act (Chapter 1 (commencing with Section 1350) of Part 4 of Division 2 of the Civil Code) might otherwise apply is exempt from that act, except for Sections 1354, 1355, 1355.5, 1356, 1357, 1358, 1361, 1361.5, 1362, 1363.05, 1364, 1365.5, 1370, and 1371 of the Civil Code.

(b) (1) To the extent that a single site time-share plan or component site of a multisite time-share plan located in the state is structured as a condominium or other common interest development, and there is any inconsistency between the applicable provisions of this chapter and the Davis-Stirling Common Interest Development Act, the applicable provisions of this chapter shall control.

(2) To the extent that a time-share plan is part of a mixed use project where the time-share plan comprises a portion of a condominium or other common interest development, the applicable provisions of this chapter shall apply to that portion of the project uniquely comprising the time-share plan, and the Davis-Stirling Common Interest Development Act shall apply to the project as a whole.

(c) (1) The offering of any time-share plan, exchange program, incidental benefit, or short term product in this state that is subject to the provisions of this chapter shall be exempt from Sections 1689.5 to 1689.14, inclusive, of the Civil Code (Home Solicitation Sales), Sections 1689.20 to 1689.24, inclusive, of the Civil Code (Seminar Sales), and Sections 1812.100 to 1812.129, inclusive, of the Civil Code (Contracts for Discount Buying Services).

(2) A developer or exchange company that, in connection with a time-share sales presentation or offer to arrange an exchange, offers a purchaser the opportunity to utilize the services of an affiliate, subsidiary, or third-party entity in connection with wholesale or retail air or sea transportation, shall not, in and of itself, cause the developer or exchange company to be considered a seller of travel subject to Sections 17550 to 17550.34, inclusive, of the Business and Professions Code, so long as the entity that actually provides or arranges the air or sea transportation is registered as a seller of travel with the California Attorney General's office or is otherwise exempt under those sections.

(d) To the extent certain sections in this chapter require information and disclosure that by their terms only apply to real property time-share plans, those requirements shall not apply to personal property time-share plans.

11212. As used in this chapter, the following definitions apply:

(a) "Accommodation" means any apartment, condominium or cooperative unit, cabin, lodge, hotel or motel room, or other private or commercial structure containing toilet facilities therein that is designed and available, pursuant to applicable law, for use and occupancy as a residence by one or more individuals, or any unit or berth on a commercial passenger ship, which is included in the offering of a time-share plan.

(b) "Advertisement" means any written, oral, or electronic communication that is directed to or targeted to persons within the state or such a communication made from this state or relating to a time-share plan located in this state and contains a promotion, inducement, or offer to sell a time-share plan, including, but not limited to, brochures, pamphlets, radio and television scripts, electronic media, telephone and direct mail solicitations, and other means of promotion.

(c) "Association" means the organized body consisting of the purchasers of time-share interests in a time-share plan.

(d) "Assessment" means the share of funds required for the payment of common expenses which is assessed from time to time against each purchaser by the managing entity.

(e) "Commissioner" means the Real Estate Commissioner.

(f) "Component site" means a specific geographic location where accommodations that are part of a multisite time-share plan are located. Separate phases of a time-share property in a specific geographic location and under common management shall not be deemed a component site.

(g) "Conspicuous type" means either of the following:

(1) Type in upper and lower case letters two point sizes larger than the nearest nonconspicuous type, exclusive of headings, on the page on which it appears but in at least 10-point type.

(2) Conspicuous type may be utilized in contracts for purchase or public permits only where required by law or as authorized by the commissioner.

(h) "Department" means the Department of Real Estate.

(i) "Developer" means and includes any person who creates a time-share plan or is in the business of selling time-share interests, other than those employees or agents of the developer who sell time-share interests on the developer's behalf, or employs agents to do the same, or any person who succeeds to the interest of a developer by sale, lease, assignment, mortgage, or other transfer, but the term includes only those persons who offer time-share interests for disposition in the ordinary course of business.

(j) "Dispose" or "disposition" means a voluntary transfer or assignment of any legal or equitable interest in a time-share plan, other than the transfer, assignment, or release of a security interest.

(k) "Exchange company" means any person owning or operating, or both owning and operating, an exchange program.

(l) "Exchange program" means any method, arrangement, or procedure for the voluntary exchange of time-share interests or other property interests. The term does not include the assignment of the right to use and occupy accommodations to owners of time-share interests within a single site time-share plan. Any method, arrangement, or procedure that otherwise meets this definition in which the purchaser's total contractual financial obligation exceeds three thousand dollars ($3,000) per any individual, recurring time-share period, shall be regulated as a time-share plan in accordance with this chapter. For purposes of determining the purchaser's total contractual financial obligation, amounts to be paid as a result of renewals and options to renew shall be included in the term except for the following: (1) amounts to be paid as a result of any optional renewal that a purchaser, in his or her sole discretion may elect to exercise, (2) amounts to be paid as a result of any automatic renewal in which the purchaser has a right to terminate during the renewal period at any time and receive a pro rata refund for the remaining unexpired renewal term, or (3) amounts to be paid as a result of an automatic renewal in which the purchaser receives a written notice no less than 30 nor more than 90 days prior to the date of renewal informing the purchaser of the right to terminate prior to the date of renewal. Notwithstanding these exceptions, if the contractual financial obligation exceeds three thousand dollars ($3,000) for any three-year period of any renewal term, amounts to be paid as a result of that renewal shall be included in determining the purchaser's total contractual financial obligation.

(m) "Incidental benefit" is an accommodation, product, service, discount, or other benefit, other than an exchange program, that is offered to a prospective purchaser of a time-share interest prior to the end of the rescission period set forth in Section 11238, the continuing availability of which for the use and enjoyment of owners of time-share interests in the time-share plan is limited to a term of not more than three years, subject to renewal or extension. The term shall not include an offer of the use of the accommodation, product, service, discount, or other benefit on a free or discounted one-time basis.

(n) "Managing entity" means the person who undertakes the duties, responsibilities, and obligations of the management of a time-share plan.

(o) "Offer" means any inducement, solicitation, or other attempt, whether by marketing, advertisement, oral or written presentation, or any other means, to encourage a person to acquire a time-share interest in a time-share plan, other than as security for an obligation.

(p) "Person" means a natural person, corporation, limited liability company, partnership, joint venture, association, estate, trust, government, governmental subdivision or agency, or other legal entity, or any combination thereof.

(q) "Promotion" means a plan or device, including one involving the possibility of a prospective purchaser receiving a vacation, discount vacation, gift, or prize, used by a developer, or an agent, independent contractor, or employee of any of the same on behalf of the developer, in connection with the offering and sale of time-share interests in a time-share plan.

(r) "Public report" means a preliminary public report, conditional public report, final public report, or other such disclosure document authorized for use in connection with the offering of time-share interests pursuant to this chapter.

(s) "Purchaser" means any person, other than a developer, who by means of a voluntary transfer for consideration acquires a legal or equitable interest in a time-share plan other than as security for an obligation.

(t) "Purchase contract" means a document pursuant to which a developer becomes legally obligated to sell, and a purchaser becomes legally obligated to buy, a time-share interest.

(u) "Reservation system" means the method, arrangement, or procedure by which a purchaser, in order to reserve the use or occupancy of any accommodation of a multisite time-share plan for one or more time-share periods, is required to compete with other purchasers in the same multisite time-share plan, regardless of whether the reservation system is operated and maintained by the multisite time-share plan managing entity, an exchange company, or any other person. If a purchaser is required to use an exchange program as the purchaser's principal means of obtaining the right to use and occupy accommodations in a multisite time-share plan, that arrangement shall be deemed a reservation system. When an exchange company utilizes a mechanism for the exchange of use of time-share periods among members of an exchange program, that utilization is not a reservation system of a multisite time-share plan.

(v) "Short-term product" means the right to use accommodations on a one-time or recurring basis for a period or periods not to exceed 30 days per stay and for a term of three years or less, and that includes an agreement that all or a portion of the consideration paid by a person for the short-term product will be applied to or credited against the price of a future purchase of a time-share interest or that the cost of a future purchase of a time-share interest will be fixed or locked-in at a specified price.

(w) "Time-share instrument" means one or more documents, by whatever name denominated, creating or governing the operation of a time-share plan and includes the declaration dedicating accommodations to the time-share plan.

(x) "Time-share interest" means and includes either of the following:

(1) A "time-share estate," which is the right to occupy a time-share property, coupled with a freehold estate or an estate for years with a future interest in a time-share property or a specified portion thereof.

(2) A "time-share use," which is the right to occupy a time-share property, which right is neither coupled with a freehold interest, nor coupled with an estate for years with a future interest, in a time-share property.

(y) "Time-share period" means the period or periods of time when the purchaser of a time-share plan is afforded the opportunity to use the accommodations of a time-share plan.

(z) "Time-share plan" means any arrangement, plan, scheme, or similar device, other than an exchange program, whether by membership agreement, sale, lease, deed, license, right to use agreement, or by any other means, whereby a purchaser, in exchange for consideration, receives ownership rights in or the right to use accommodations for a period of time less than a full year during any given year, on a recurring basis for more than one year, but not necessarily for consecutive years. A time-share plan may be either of the following:

(1) A "single site time-share plan," which is the right to use accommodations at a single time-share property.

(2) A "multisite time-share plan," which includes either of the following:

(A) A "specific time-share interest," which is the right to use accommodations at a specific time-share property, together with use rights in accommodations at one or more other component sites created by or acquired through the time-share plan's reservation system.

(B) A "nonspecific time-share interest," which is the right to use accommodations at more than one component site created by or acquired through the time-share plan's reservation system, but including no specific right to use any particular accommodations.

(aa) "Time-share property" means one or more accommodations subject to the same time-share instrument, together with any other property or rights to property appurtenant to those accommodations.

11213. Each time-share estate, as specified in paragraph (1) of subdivision (x) of Section 11212, constitutes, for purposes of title, a separate estate or interest in real property including ownership in real property for tax purposes.

11214. (a) The developer shall supervise, manage, and control all aspects of the offering of the time-share plan by or on behalf of the developer, including, but not limited to, promotion, advertising, contracting, and closing. The developer is responsible for each time-share plan registered with the commissioner and for the actions of any sales or marketing entity utilized by the developer in the offering or selling of any registered time-share plan.

(b) Any violation of this chapter that occurs during the offering activities shall be deemed to be a violation by the developer as well as by the person who actually committed the violation.

11215. (a) The time-share instrument shall prohibit a person from seeking or obtaining, through any legal procedures, judicial partition of the time-share interest or sale of the time-share interest, in lieu of partition and shall subordinate all rights that a time-share interest owner might otherwise have as a tenant-in-common in real property to the terms of the time-share instrument.

(b) Subdivision (a) shall not be deemed to prohibit a sale of an accommodation upon termination of the time-share plan or the removal of an accommodation from the time-share plan in accordance with applicable provisions of the time-share instrument.

11216. (a) An exchange program is not a part of a time-share plan offering and, except as provided in this section and Section 11238, shall not be subject to either this chapter or the regulations of the commissioner adopted pursuant to this chapter.

(b) If a developer offers a purchaser the opportunity to subscribe to or to become a member of an exchange program, the developer shall provide to the purchaser in writing all of the information set forth in paragraphs (1) to (17), inclusive. If the exchange company is offering directly to the purchaser the opportunity to subscribe to or become a member of an exchange company, the exchange company shall provide to the purchaser in writing all of the information set forth in paragraphs (1) to (17), inclusive. In either case, the written information shall be provided prior to or concurrently with the execution of any contract or subscription for membership in the exchange program.

(1) The name and address of the exchange company.

(2) The names of all officers, directors, and shareholders of the exchange company.

(3) Whether the exchange company or any of its officers or directors have any legal or beneficial interest in any developer or managing entity for any time-share plan participating in the exchange program and, if so, the identity of the time-share plan and the nature of the interest.

(4) A copy of the form of the contract between the purchaser and the exchange company, along with a statement that the purchaser's contract with the exchange company is a contract separate and distinct from the purchaser's contract with the seller of time-share interests.

(5) Whether the purchaser's participation in the exchange program is dependent upon the continued affiliation of the applicable time-share plan with the exchange program.

(6) Whether the purchaser's participation in the exchange program is voluntary.

(7) A fair and accurate description of the terms and conditions of the purchaser's contractual relationship with the exchange program and the procedure by which changes thereto may be made.

(8) A fair and accurate description of the procedures necessary to qualify for and effectuate exchanges.

(9) A fair and accurate description of all limitations, restrictions, and priorities employed in the operation of the exchange program, including, but not limited to, limitations on exchanges based on seasonality, accommodation size, or levels of occupancy, expressed in conspicuous type. If those limitations, restrictions, or priorities are not uniformly applied by the exchange company, the information shall include a clear description of the manner in which they are applied.

(10) Whether exchanges are arranged on a space available basis and whether any guarantees of fulfillment of specific requests for exchanges are made by the exchange company.

(11) Whether and under what circumstances an owner, in dealing with the exchange program, may lose the right to use and occupy an accommodation of the time-share plan during a reserved use period with respect to any properly applied for exchange without being provided with substitute accommodations by the exchange program.

(12) The fees or range of fees for participation by owners in the exchange program, a statement of whether any such fees may be altered by the exchange company and the circumstances under which alterations may be made.

(13) The name and address of the site of each accommodation included within a time-share plan participating in the exchange program.

(14) The number of accommodations in each time-share plan that are

available for occupancy and that qualify for participation in the

exchange program, expressed within the following numerical groups:

1-5; 6-10; 11-20; 21-50; and 51 and over.

(15) The number of currently enrolled owners for each time-share

plan participating in the exchange program, expressed within the

following numerical groups: 1-100; 101-249; 250-499; 500-999; and

1,000 and over; and a statement of the criteria used to determine

those owners who are currently enrolled with the exchange program.

(16) The disposition made by the exchange company of use periods

deposited with the exchange program by owners enrolled in the

exchange program and not used by the exchange company in effecting

exchanges.

(17) The following information for the preceding calendar year,

which shall be independently audited by a certified public accountant

in accordance with the standards of the Accounting Standards Board

of the American Institute of Certified Public Accountants and

reported annually no later than August 1 of each year:

(A) The number of owners currently enrolled in the exchange

program.

(B) The number of time-share plans that have current affiliation

agreements with the exchange program.

(C) The percentage of confirmed exchanges, which is the number of

exchanges confirmed by the exchange program divided by the number of

exchanges properly applied for, together with a complete and accurate

statement of the criteria used to determine whether an exchange

request was properly applied for.

(D) The number of use periods for which the exchange program has

an outstanding obligation to provide an exchange to an owner who

relinquished a use period during a particular year in exchange for a

use period in any future year.

(E) The number of exchanges confirmed by the exchange program

during the year.

(F) A statement in conspicuous type to the effect that the

percentage described in subparagraph (C) is a summary of the exchange

requests entered with the exchange program in the period reported

and that the percentage does not indicate the probabilities of an

owner's being confirmed to any specific choice or range of choices.

(c) All written, visual, and electronic communications relating to

an exchange company or an exchange program shall be filed with the

commissioner upon its request.

(d) The failure of an exchange company to observe the requirements

of this section, and the use of any unfair or deceptive act or

practice in connection with the operation of an exchange program, is

a violation of this chapter.

(e) An exchange company may elect to deny exchange privileges to

any owner whose use of the accommodations of the owner's time-share

plan is denied, and no exchange program or exchange company shall be

liable to any of its members or any third parties on account of any

such denial of exchange privileges.

11217. (a) The following communications shall not be deemed an

advertisement or promotion and are exempt from this chapter so long

as the communications are in compliance with Section 11245:

(1) Any stockholder communication, such as an annual report or

interim financial report, proxy material, a registration statement, a

securities prospectus, a registration, a property report, or other

material required to be delivered to a prospective purchaser by an

agency of any state or the federal government.

(2) Any oral or written statement disseminated by a developer to

broadcast or print media, other than paid advertising or promotional

material, regarding plans for the acquisition or development of

time-share property. However, any rebroadcast or any other

dissemination of the oral statements to a prospective purchaser by a

developer or any person in any manner, or any distribution of copies

of newspaper magazine articles or press releases, or any other

dissemination of the written statements to a prospective purchaser by

a developer or any person in any manner, shall constitute an

advertisement.

(3) Any advertisement or promotion in any medium to the general

public if the advertisement or promotion clearly states that it is

not an offer in any jurisdiction in which any applicable registration

requirements have not been fully satisfied.

(4) Any audio, written, or visual publication or material relating

to the availability of any accommodations for transient rental, so

long as a sales presentation is not a term or condition of the

availability of the accommodations and so long as the failure of any

transient renter to take a tour of a time-share property or attend a

sales presentation does not result in any reduction in the level of

services that would otherwise be available to the transient renter.

(b) Any communication regarding a time-share interest that is

addressed to any person who has previously executed a contract for

the sale or purchase of that time-share interest and that does not

constitute a solicitation of a time-share interest, shall be exempt

from this chapter.

11218. A time-share interest in a time-share plan shall be deemed

an interest in subdivided lands or a subdivision for purposes of

subdivision (f) of Section 25100 of the Corporations Code.

11219. (a) Time-share plans registered as Qualified Resort

Vacation Club Projects under prior law shall continue to operate

under that prior law notwithstanding anything in this chapter to the

contrary.

(b) (1) All registrations of time-share plans in effect on the

effective date of this chapter shall remain in full force and effect

and shall be considered registered pursuant to this chapter.

(2) All time-share plans included in this subdivision are subject

to Sections 11217, 11219, 11238, 11239, 11245, 11250, and 11280 to

11286, inclusive, and shall be required to comply with the other

provisions of this chapter at the time they seek amendment or renewal

of their existing registrations. When an amendment or renewal of a

time-share plan is filed with the commissioner, the existing

registration continues in full force and effect while the amendment

or renewal is pending before the commissioner.

(c) Any existing injunction or temporary restraining order validly

obtained that prohibits unregistered practice of time-share

developers, time-share plans, or their agents shall not be

invalidated by the enactment of this chapter and shall continue to

have full force and effect on and after the effective date of this

chapter.

 

Article 2. Registration, Sale Requirements, and Fees

 

11225. A person shall not be required to register a time-share

plan with the commissioner pursuant to this chapter if any of the

following applies:

(a) The person is an owner of a time-share interest who has

acquired the time-share interest for the person's own use and

occupancy and who later offers it for resale.

(b) The person is a managing entity or an association that is not

otherwise a developer of a time-share plan in its own right, solely

while acting as an association or under a contract with an

association to offer or sell a time-share interest transferred to the

association through foreclosure, deed in lieu of foreclosure, or

gratuitous transfer, if these acts are performed in the regular

course of, or as an incident to, the management of the association

for its own account in the time-share plan. Notwithstanding the

exemption from registration, the association or managing entity shall

provide each purchaser of a time-share interest covered by this

subdivision a copy of the time-share instruments, a copy of the

then-current budget, a written statement of the then-current

assessment amounts, and shall provide the purchaser the opportunity

to rescind the purchase within seven days after receipt of these

documents. Immediately prior to the space reserved in the contract

for the signature of the purchaser, the association or managing

entity shall disclose, in conspicuous type, substantially the

following notice of cancellation:

YOU MAY CANCEL THIS CONTRACT WITHOUT ANY PENALTY OR OBLIGATION

WITHIN SEVEN CALENDAR DAYS OF RECEIPT OF THE PUBLIC REPORT OR AFTER

THE DATE YOU SIGN THIS CONTRACT, WHICHEVER DATE IS LATER. IF YOU

DECIDE TO CANCEL THIS CONTRACT, YOU MUST NOTIFY THE ASSOCIATION (OR

MANAGING ENTITY) IN WRITING OF YOUR INTENT TO CANCEL. YOUR NOTICE OF

CANCELLATION SHALL BE EFFECTIVE UPON THE DATE SENT AND SHALL BE SENT

TO (NAME OF ASSOCIATION OR MANAGING ENTITY) AT (ADDRESS OF

ASSOCIATION OR MANAGING ENTITY). YOUR NOTICE OF CANCELLATION MAY

ALSO BE SENT BY FACSIMILE TO (FACSIMILE NUMBER OF THE ASSOCIATION OR

MANAGING ENTITY) OR BY HAND-DELIVERY. ANY ATTEMPT TO OBTAIN A WAIVER

OF YOUR CANCELLATION RIGHT IS VOID AND OF NO EFFECT.

 

(c) The person is conveyed, assigned, or transferred more than

seven time-share interests from a developer in a single voluntary or

involuntary transaction and subsequently conveys, assigns, or

transfers all of the time-share interests received from the developer

to a single purchaser in a single transaction.

(d) (1) The developer is offering or disposing of a time-share

interest to a purchaser who has previously acquired a time-share

interest from the same developer if the developer has a time-share

plan registered under this chapter, which was originally approved by

the commissioner within the preceding seven years, and the developer

complies in all respects with the provisions of Section 11245, and,

further, provides the purchaser with (A) a cancellation period of at

least seven days, (B) all the time-share disclosure documents that

are required to be provided to purchasers as if the sale occurred in

the state or jurisdiction where the time-share property is located,

and (C) the following disclaimer in conspicuous type:

WARNING: THE CALIFORNIA DEPARTMENT OF REAL ESTATE HAS NOT EXAMINED

THIS OFFERING, INCLUDING, BUT NOT LIMITED TO, THE CONDITION OF TITLE,

THE STATUS OF BLANKET LIENS ON THE PROJECT (IF ANY), ARRANGEMENTS TO

ASSURE PROJECT COMPLETION, ESCROW PRACTICES, CONTROL OVER PROJECT

MANAGEMENT, RACIALLY DISCRIMINATORY PRACTICES (IF ANY), TERMS,

CONDITIONS, AND PRICE OF THE OFFER, CONTROL OVER ANNUAL ASSESSMENTS

(IF ANY), OR THE AVAILABILITY OF WATER, SERVICES, UTILITIES, OR

IMPROVEMENTS. IT MAY BE ADVISABLE FOR YOU TO CONSULT AN ATTORNEY OR

OTHER KNOWLEDGEABLE PROFESSIONAL WHO IS FAMILIAR WITH REAL ESTATE AND

DEVELOPMENT LAW IN THE STATE WHERE THIS TIME-SHARE PROPERTY IS

SITUATED.

 

(2) By making such an offering or disposition, the person is

deemed to consent to the jurisdiction of the commissioner in the

event of a dispute with the purchaser in connection with the offering

or disposition.

(e) It is a single site time-share plan located outside of the

boundaries of the United States or component site of a specific

time-share interest multisite time-share plan located wholly outside

of the boundaries of the United States, or a nonspecific time-share

interest multisite time-share plan in which all component sites are

located wholly outside of the boundaries of the United States.

However, it is unlawful and a violation of this chapter for a person,

in this state, to sell or lease or offer for sale or lease a

time-share interest in such a time-share plan, located outside the

United States, unless the printed material, literature, advertising,

or invitation in this state relating to that sale, lease, or offer

clearly and conspicuously contains the following disclaimer in

capital letters of at least 10-point type:

WARNING: THE CALIFORNIA DEPARTMENT OF REAL ESTATE HAS NOT EXAMINED

THIS OFFERING, INCLUDING, BUT NOT LIMITED TO, THE CONDITION OF

TITLE, THE STATUS OF BLANKET LIENS ON THE PROJECT (IF ANY),

ARRANGEMENTS TO ASSURE PROJECT COMPLETION, ESCROW PRACTICES, CONTROL

OVER PROJECT MANAGEMENT, RACIALLY DISCRIMINATORY PRACTICES (IF ANY),

TERMS, CONDITIONS, AND PRICE OF THE OFFER, CONTROL OVER ANNUAL

ASSESSMENTS (IF ANY), OR THE AVAILABILITY OF WATER, SERVICES,

UTILITIES, OR IMPROVEMENTS. IT MAY BE ADVISABLE FOR YOU TO CONSULT

AN ATTORNEY OR OTHER KNOWLEDGEABLE PROFESSIONAL WHO IS FAMILIAR WITH

REAL ESTATE AND DEVELOPMENT LAW IN THE COUNTRY WHERE THIS TIME-SHARE

PROPERTY IS SITUATED.

 

(1) If an offer of time-share interest in a time-share plan

described in subdivision (e) is not initially made in writing, the

foregoing disclaimer shall be received by the offeree in writing

prior to a visit to a location, sales presentation, or contact with a

person representing the offeror, when the visit or contact was

scheduled or arranged by the offeror or its representative. The

deposit of the disclaimer in the United States mail, addressed to the

offeree and with first-class postage prepaid, at least five days

prior to the scheduled or arranged visit or contact, shall be deemed

to constitute delivery for purposes of this section.

(2) If any California resident is presented with an agreement or

purchase contract to lease or purchase a time-share interest as

described in subdivision (e), where an offer to lease or purchase

that time-share interest was made to that resident in California, a

copy of the disclaimer set forth in subdivision (e) shall be inserted

in at least 10-point type at the top of the first page of that

agreement or purchase contract and shall be initialed by that

California resident.

(3) Nothing contained in this subdivision shall be deemed to

exempt from registration in this state a nonspecific time-share

interest multisite time-share plan in which any component site in the

time-share plan is located in the United States.

11226. (a) Any person who, to any individual located in the

state, sells, offers to sell, or attempts to solicit prospective

purchasers to purchase a time-share interest, or any person who

creates a time-share plan with an accommodation in the state, shall

register the time-share plan with the commissioner, unless the

time-share plan is otherwise exempt under this chapter.

(b) A developer, or any of its agents, shall not sell, offer, or

dispose of a time-share interest in the state unless all necessary

registration

requirements are provided and approved by the commissioner, or the

sale, offer, or disposition is otherwise permitted by this chapter,

or while an order revoking or suspending a registration is in effect.

 

(c) In registering a time-share plan, the developer shall provide

all of the following information:

(1) The developer's legal name, any assumed names used by the

developer, principal office street address, mailing address, primary

contact person, and telephone number.

(2) The name of the developer's authorized or registered agent in

the state upon whom claims can be served or service of process be

had, the agent's street address in California, and telephone number.

 

(3) The name, street address, mailing address, primary contact

person, and telephone number of any time-share plan being registered.

 

(4) The name, street address, mailing address, and telephone

number of any managing entity of the time-share plan.

(5) A public report that complies with the requirements of Section

11234 or for a time-share plan located outside of the state a public

report that has been authorized for use by the situs state

regulatory agency and that contains disclosures as determined by the

commissioner upon review to be substantially equivalent to or greater

than the information required to be disclosed pursuant to Section

11234.

(6) A description of the inventory control system that will ensure

compliance with Section 11250.

(7) Any other information regarding the developer, time-share

plan, or managing entities as established by regulation.

(d) An applicant for a public report for a time-share plan shall

present evidence of the following for each accommodation of the

time-share plan:

(1) That the accommodation is presently suitable for human

occupancy or that financial arrangements have been made to complete

construction or renovation of the accommodation to make it suitable

for human occupancy on or before the first date for occupancy by a

time-share interest owner.

(2) That the accommodation is owned or leased by the developer of

the time-share plan or is the subject of an enforceable option or

contract under which the developer will build, purchase, or lease the

accommodation. Notwithstanding this subdivision, the developer

shall present evidence prior to the receipt of a final public report

that the accommodation to be sold is owned or leased by the developer

and that the accommodation is free and clear of encumbrances in

accordance with Sections 11244 and 11255.

(e) If an accommodation in a time-share plan is located within a

local governmental jurisdiction or subdivision of real property in

which the dedication of accommodations to time-sharing is expressly

prohibited by ordinance or recorded restriction, either absolutely or

without a permit or other entitlement from the governing body, the

applicant for a public report shall present evidence of a permit or

other entitlement by the appropriate authority for the local

government or the subdivision.

(f) (1) The developer shall amend or supplement its disclosure

documents and registration information, to reflect any material

change in any information required by this chapter or the regulations

implementing this chapter. The developer shall notify the

commissioner of the material change prior to implementation of the

change, unless the change is beyond the control of the developer; in

which event, the developer shall provide written notice to the

commissioner as soon as reasonably practicable after the occurrence

of the event necessitating the change. All amendments, supplements,

and facts relevant to the material change shall be filed with the

commissioner within 20-calendar days of the material change.

(2) The developer may continue to sell time-share interests in the

time-share plan so long as, prior to closing, the developer provides

a notice to each purchaser that describes the material change and

provides to each purchaser the previously approved public report.

(A) If the change is material and adverse to the purchaser, all

purchaser funds shall be held in escrow, or pursuant to alternative

assurances permitted by subdivision (c) of Section 11243, and no

closing shall occur until the amendment relating to the material and

adverse change has been approved by the commissioner. After the

amendment relating to the material and adverse change has been

approved and the amended public report has been issued, the amended

public report shall be sent to the purchaser, and an additional

seven-day rescission period shall commence. The developer shall be

required to maintain evidence of the receipt by each such purchaser

of the amended public report.

(B) If the commissioner refuses to approve the amendment relating

to the material and adverse change, all sales made using the notice

shall be subject to rescission and all funds returned.

(3) The developer shall update the public report to reflect any

changes to the time-share plan that are not material and adverse,

including the addition of any component sites, within a reasonable

time, and may continue to sell and close time-share interests prior

to the date that the amended public report is approved.

11227. (a) Subject to subdivision (h), the commissioner shall

issue a final public report if all registration requirements have

been met as set forth in this chapter and if all deficiencies and

substantive inadequacies in the substantially complete application

for a final public report for the time-share plan have been

corrected.

(b) The commissioner may issue a conditional public report prior

to issuing a final public report for a time-share plan if the

requirements of subdivision (c) are met, all deficiencies and

substantive inadequacies in the substantially complete application

for a final public report for the time-share plan have been

corrected, the material elements of the offering to be made under the

authority of the conditional public report have been established,

and all requirements for the issuance of the conditional public

report have been met, except for one or more of the following

requirements, as may be applicable:

(1) A final map has not been recorded.

(2) A condominium plan has not been recorded.

(3) A declaration of covenants, conditions, and restrictions has

not been recorded.

(4) A declaration of annexation has not been recorded.

(5) A recorded subordination of existing liens to the time-share

instruments or declaration of annexation or escrow instructions to

effect recordation prior to the first sale, are lacking.

(6) Filed articles of incorporation are lacking.

(7) A current preliminary report of a licensed title insurance

company issued after filing of the final map and recording of the

time-share instrument covering all time-share interests to be

included in the public report has not been provided.

(8) Other requirements the commissioner determines are likely to

be timely satisfied by the applicant.

(c) An applicant for a conditional public report shall submit the

following information and documents with the applicable filing fee:

(1) A copy of the statement set forth in subdivision (e).

(2) A sales agreement or lease to be used in any transaction

conducted under authority of the conditional public report. The

sales agreement or lease shall include all of the following

provisions:

(A) No escrow will close, funds will not be released from escrow,

and the interest contracted for will not be conveyed until a current

final public report for the time-share plan is furnished to the

purchaser.

(B) The contract may be rescinded, in which event the entire sum

of money paid or advanced by the purchaser shall be returned if (i) a

final public report has not been issued within six months after the

date of issuance of the conditional public report if the conditional

public report is not renewed, (ii) the final public report is not

issued within 12 months after the initial conditional public report

is received if the conditional public report has been renewed for an

additional six-month period, or (iii) the purchaser or lessee is

dissatisfied with the final public report because of a material and

adverse change.

(3) Escrow instructions to be used in any transaction conducted

under authority of the conditional public report that includes at

least the following information:

(A) The name and address of the escrow depository.

(B) A description of the nature of the transaction.

(C) Provisions ensuring compliance with Section 11243.

(D) Provisions ensuring that no escrow will close, funds will not

be released from escrow, and the interest contracted for will not be

conveyed until a current final public report for the time-share plan

is furnished to the purchaser or lessee.

(E) Provisions for the return of money as prescribed in

subparagraph (B) of paragraph (2).

(d) A decision by the commissioner to not issue a conditional

public report shall be noticed in writing to the applicant within

five business days after his or her decision and that notice shall

specifically state the reasons why the report is not being issued.

(e) A person may sell or lease, or offer for sale or lease,

time-share interests in a time-share plan pursuant to a conditional

public report if, as a condition of the sale or lease or offer for

sale or lease, delivery of legal title or other interest contracted

for will not take place until issuance of a final public report and

provided that the requirements of subdivision (c) are met.

(f) A developer, principal, or his or her agent shall provide a

prospective purchaser a copy of the conditional public report and a

written statement including all of the following information:

(1) Specification of the information required for issuance of a

final public report.

(2) Specification of the information required in the final public

report that is not available in the conditional public report, along

with a statement of the reasons why that information is not available

at the time of issuance of the conditional public report.

(3) A statement that no person acting as a principal or agent

shall sell or lease, or offer for sale or lease, time-share interests

in a time-share plan for which a conditional public report has been

issued except as provided in this chapter.

(4) Specification of the requirements of subdivision (e).

(g) The prospective purchaser shall sign a receipt that he or she

has received and has read the conditional public report and the

written statement provided pursuant to subdivision (f).

(h) The term of a conditional public report may not exceed six

months unless renewed pursuant to this subdivision. The conditional

public report may be renewed for one additional six-month period if

the commissioner determines that the requirements for issuance of a

final public report are likely to be satisfied during the renewal

term. The renewal of a conditional public report shall not act to

afford a purchaser who received the initial conditional public report

any additional rescission rights other than those provided to a

purchaser when a final public report is issued and a material and

adverse change has been made.

(i) For single site time-share plans and component sites of a

multisite time-share plan located outside of the state, a disclosure

document that has been authorized for use by the state regulatory

agency in the state in which the time-share plan or component site is

located that contains the disclosures as determined by the

commissioner upon review to be substantially equivalent to or greater

than the information required to be disclosed pursuant to Section

11234, shall be accepted in lieu of a public report required pursuant

to this section. The disclosure document shall contain a cover page

issued by the commissioner certifying the approval of its use in

lieu of the public report required herein.

(j) Notwithstanding anything in this section to the contrary, the

commissioner may grant a 12-month preliminary public report allowing

the developer to begin offering and selling time-share interests, in

a time-share plan regardless of whether the accommodations of the

time-share plan are located within or outside of the state, while the

registration is pending with the commissioner. The commissioner may

grant one additional 12-month period if the developer is actively

and diligently pursuing registration under this chapter. The

preliminary public report shall automatically terminate with respect

to those time-share interests covered by a final public report that

is issued before the scheduled termination date of the preliminary

report. To obtain a preliminary public report, the developer shall

provide all of the following:

(1) Submit the reservation instrument to be used in a form

previously approved by the department with at least the following

provisions:

(A) The right of both the developer and the potential purchaser to

unilaterally cancel the reservation at any time.

(B) The payment to the potential purchaser of his or her total

deposit following cancellation of the reservation by either party.

(C) The placing of the deposit into an interest bearing escrow

account.

(2) Agree to provide each potential purchaser with a copy of the

preliminary public report and an executed receipt for a copy before

any money or other thing of value has been accepted by or on behalf

of the developer in connection with the reservation.

(3) Agree to provide a copy of the reservation instrument signed

by the potential purchaser and by or on behalf of the developer to

the potential purchaser, and place any deposit taken from the

potential purchaser into a neutral escrow depository acceptable to

the commissioner.

11228. The term of a final public report shall be limited to five

years. A renewal shall be issued if the developer, owner, or agent

makes application for renewal of any report and has submitted the

additional information that the commissioner may require.

11229. (a) In connection with its review of the registration

application of a time-share plan, the commissioner may make an

examination of any time-share property submitted for registration

pursuant to this chapter, and shall, unless there are grounds for

denial, issue to the developer a public report authorizing the sale

or lease in this state of the time-share interests within the

time-share plan submitted pursuant to this chapter. The report shall

contain the data obtained in accordance with Section 11234.

(b) The commissioner may deny the issuance of the public report

based on the applicant's failure to comply with any of the provisions

of this chapter or the regulations of the commissioner pertaining

thereto, including, but not limited to, all of the following:

(1) The sale or lease would constitute misrepresentation to, or

deceit or fraud of, the purchasers or lessees.

(2) Inability to deliver title or other interest contracted for.

(3) Inability to demonstrate, in accordance with this chapter,

that adequate financial arrangements have been made for all offsite

improvements included in the offering.

(4) Inability to demonstrate, in accordance with this chapter,

that adequate financial arrangements have been made for any

community, recreational, or other facilities included in the

offering.

(5) Failure to make a showing that the parcels can be used for the

purpose for which they are offered.

(6) Failure to provide in the contract or other writing the use or

uses for which the parcels are offered, together with any covenants

or conditions relative thereto.

(c) Any developer objecting to the denial of a public report may,

within 30 days after receipt of the order of denial, file a written

request for a hearing. The commissioner shall hold the hearing

within 20 days thereafter unless the party requesting the hearing

requests a postponement. If the hearing is not held within 20 days

after request for a hearing is received plus the period of the

postponement or if a proposed decision is not rendered within 45 days

after submission and an order adopting or rejecting the proposed

decision is not issued within 15 days thereafter, the order of denial

shall be rescinded and a public report issued.

11230. If the time-share plan, including any accommodations, or

amenities within the common area are not completed prior to the

issuance of a final public report for the time-share plan, the

developer shall specify a reasonable date for completion and shall

comply with any one of the following conditions:

(a) Arranges for lien and completion bond or bonds, enforceable by

the association, in an amount and subject to the terms, conditions,

and coverage necessary to assure completion of the improvements

lien-free. The bond shall not exceed 120 percent of the cost for

completion, and the bond shall provide for the reduction of the bond

amount as work is completed.

(b) All funds from the sale of time-share interests as the

commissioner shall determine are sufficient to assure construction of

the improvement or improvements shall be bonded or impounded in a

neutral escrow depository acceptable to the commissioner until the

improvements have been completed and all applicable lien periods have

expired.

(c) An amount sufficient to cover the costs of construction shall

be deposited in a neutral escrow depository acceptable to the

commissioner under a written escrow agreement providing for

disbursements from the escrow as work is completed.

(d) An alternative plan that may be approved by the commissioner.

 

11231. Every registration required to be filed with the

commissioner under this chapter shall be reviewed and issued the

specified public report in accordance with the following schedule:

(a) Time-share registration. Registration shall be effective only

upon the issuance of a public report by the commissioner that shall

occur no later than 60 calendar days after the actual receipt by the

commissioner of the properly completed application. The commissioner

shall provide a list of deficiencies in the application, if any,

within 60 calendar days of receipt. This same time period applies

when amending a public report to add additional phases or component

sites of the time-share plan.

(b) Preliminary public report registration. A preliminary public

report shall be issued within 15 calendar days of receipt, unless the

commissioner provides to the applicant a written list of

deficiencies in the application, if any, within 15 calendar days of

receipt of an application.

(c) Amended public report where no additional phases or component

sites are added. An effective date for an amendment to a public

report should occur no more than 45 calendar days after actual

receipt by the commissioner of the amendment. The commissioner shall

provide a list of deficiencies regarding the amendments, if any,

within 45 calendar days of receipt.

11232. (a) The commissioner may by regulation prescribe filing

fees in connection with applications to the Department of Real Estate

for a public report pursuant to the provisions of this chapter that

are lower than the maximum fees specified in subdivision (b) if the

commissioner determines that the lower fees are sufficient to offset

the costs and expenses incurred in the administration of this

chapter. The commissioner shall hold at least one hearing each

calendar year to determine if lower fees than those specified in

subdivision (b) should be prescribed.

(b) The filing fees for an application for a public report to be

issued under authority of this chapter shall not exceed the following

for each time-share plan, location, or phase of the time-share plan

in which interests are to be offered for sale or lease:

(1) One thousand seven hundred dollars ($1,700) plus ten dollars

($10) for each time-share interest to be offered for an original

public report application.

(2) Six hundred dollars ($600) plus ten dollars ($10) for each

time-share plan interest to be offered that was not permitted to be

offered under the public report to be renewed for a renewal public

report or permit application.

(3) Five hundred dollars ($500) plus ten dollars ($10) for each

time-share interest to be offered under the amended public report for

which a fee has not previously been paid for an amended public

report application.

(4) Five hundred dollars ($500) for a conditional public report

application.

(c) Fees collected by the commissioner under authority of this

chapter shall be deposited into the Real Estate Fund pursuant to

Chapter 6 (commencing with Section 10450) of Part 1. Fees received

by the commissioner pursuant to this article shall be deemed earned

upon receipt. No part of any fee is refundable unless the

commissioner determines that it was paid as a result of mistake or

inadvertency. This section shall remain in effect unless it is

superseded pursuant to Section 10266 or subdivision (a) of Section

10266.5, whichever is applicable.

11233. An applicant for a public report for a time-share plan in

which the use and occupancy of the time-share interest purchased in

the time-share plan is determined according to a point system shall

include in the application the following information:

(a) Whether additional points may be acquired by purchase or

otherwise, in the future and the manner in which future purchases of

points may be made.

(b) The transferability of points to other persons, other years or

other time-share plans.

(c) A copy of the then-current point value use directory, along

with rules and procedures for changes by the developer or the

association in the manner in which point values may be used.

(1) No change exceeding 10 percent per annum in the manner in

which point values may be used may be made without the assent of at

least 25 percent of the voting power of the association other than

the developer.

(2) No time-share interest owner shall be prevented from using a

time-share plan as a result of changes in the manner in which point

values may be used.

(3) In the event point values are changed or adjusted, no

time-share owner shall be prevented from using his or her home resort

in the same manner as was provided for under the original purchase

contract.

(d) Any limitations or restrictions upon the use of point values.

 

(e) A description of an inventory control system that will ensure

compliance with Section 11250.

11234. A developer shall prepare, for issuance by the

commissioner, a public report that shall fully and accurately

disclose those facts concerning the time-share developer and

time-share plan that are required by this chapter or by regulation.

The developer shall provide the public report to each purchaser of a

time-share interest in any time-share plan at the time of purchase.

The public report shall be in writing and dated and shall require the

purchaser to certify in writing the receipt thereof. The public

report for a single site time-share plan is subject to the

requirements of subdivision (a). The public report for a specific

time-share interest multisite time-share plan is subject to the

requirements of both subdivisions (a) and (b). The public report for

a nonspecific time-share interest multisite time-share plan is

subject to the requirements of subdivision (c). For time-share plans

located outside of the state, a public report that has been

authorized for use by the situs state regulatory agency and that

contains disclosures as determined by the commissioner upon review to

be substantially equivalent to or greater than the information

required to be disclosed pursuant to this section may be used by the

developer to meet the requirements of this section.

(a) Public reports for a single site and those component sites of

a specific time-share interest multisite time-share plan that are

offered in this state shall include the following:

(1) The name and address of the developer and the type of

time-share plan being offered and the name and address of the

time-share project.

(2) A description of the existing or proposed accommodations,

including the type and number of time-share interests in the

accommodations, and if the accommodations are proposed or not yet

complete or fully functional, an estimated date of completion.

(3) The number of accommodations and time-share interests,

expressed in periods of seven-day use availability or other time

increments applicable to the time-share plan, committed to the

multisite time-share plan, and available for use by purchasers and a

representation about the percentage of useable time authorized for

sale, and if that percentage is 100 percent, then a statement

describing how adequate periods of time for maintenance and repair

will be provided.

(4) A description of any existing or proposed amenities of the

time-share plan and, if the amenities are proposed or not yet

complete or fully functional, the estimated date of completion.

(5) The extent to which financial arrangements have been made for

the completion of any incomplete, promised improvements.

(6) A description of the duration, phases, and operation of the

time-share plan.

(7) The name and principal address of the managing entity and a

description of the procedures, if any, for altering the powers and

responsibilities of the managing entity and for removing or replacing

it.

(8) The current annual budget as required by Section 11240, along

with the projected assessments and a description of the method for

calculating and apportioning the assessments among purchasers, all of

which shall be attached as an exhibit to the public report.

(9) Any initial or special fee due from the purchaser at closing

together with a description of the purpose and the method of

calculating the fee.

(10) A description of any financing offered by or available

through the developer.

(11) A description of any liens, defects, or encumbrances on or

affecting the title to the time-share interests.

(12) A description of any bankruptcies, pending civil or criminal

suits, adjudications, or disciplinary actions of which the developer

has knowledge, that would have a material effect on the developer's

ability to perform its obligations.

(13) Any current or expected fees or charges to be paid by

time-share purchasers for the use of any amenities related to the

time-share plan.

(14) A description and amount of insurance coverage provided for

the protection of the purchaser.

(15) The extent to which a time-share interest may become subject

to a tax lien or other lien arising out of claims against purchasers

of different

time-share interests.

(16) A statement disclosing any right of first refusal or other

restraint on the transfer of all or any portion of a time-share

interest.

(17) A statement disclosing that any deposit made in connection

with the purchase of a time-share interest shall be held by an escrow

agent until expiration of any right to cancel the contract and that

any deposit shall be returned to the purchaser if he or she elects to

exercise his or her right of cancellation. Alternatively, if the

commissioner has accepted from the developer a surety bond,

irrevocable letter of credit, or other financial assurance, each of

which shall be enforceable by the association, in lieu of placing

deposits in an escrow account: (A) a statement disclosing that the

developer has provided a surety bond, irrevocable letter of credit,

or other financial assurance in an amount equal to or in excess of

the funds that would otherwise be placed in an escrow account, (B) a

description of the type of financial assurance that has been

obtained, (C) a statement that if the purchaser elects to exercise

his or her right of cancellation as provided in the contract, the

developer shall return the deposit, and (D) a description of the

person or entity to whom the purchaser should apply for payment.

(18) A statement that the assessments collected from the

purchasers will be kept in a segregated account separate from the

assessments collected from the purchasers of other time-share plans

managed by the same managing entity, along with a statement

identifying the location of the account and a disclosure of the

rights of owners to inspect the records pertaining to their accounts.

 

(19) If the time-share plan provides purchasers with the

opportunity to participate in an exchange program, a description of

the name and address of the exchange company and the method by which

a purchaser accesses the exchange program.

(20) Any other information that the developer, with the approval

of the commissioner, desires to include in the public report.

(21) Any other information reasonably requested by the

commissioner.

(b) Public reports for specific time-share interest multisite

time-share plans shall include the following additional disclosures:

 

(1) A description of each component site, including the name and

address of each component site.

(2) The number of accommodations and time-share interests,

expressed in periods of seven-day use availability or other time

increments applicable to each component site of the time-share plan,

committed to the multisite time-share plan and available for use by

purchasers and a representation about the percentage of useable time

authorized for sale, and if that percentage is 100 percent, then a

statement describing how adequate periods of time for maintenance and

repair will be provided.

(3) Each type of accommodation in terms of the number of bedrooms,

bathrooms, and sleeping capacity, and a statement of whether or not

the accommodation contains a full kitchen. For purposes of this

description, a "full kitchen" means a kitchen having a minimum of a

dishwasher, range, sink, oven, and refrigerator.

(4) A description of amenities available for use by the purchaser

at each component site.

(5) A description of the reservation system, which shall include

the following:

(A) The entity responsible for operating the reservation system,

its relationship to the developer, and the duration of any agreement

for operation of the reservation system.

(B) A summary of the rules and regulations governing access to and

use of the reservation system.

(C) The existence of and an explanation regarding any priority

reservation features that affect a purchaser's ability to make

reservations for the use of a given accommodation on a

first-come-first-served basis.

(6) The name and principal address of the managing entity for the

multisite time-share plan and a description of the procedures, if

any, for altering the powers and responsibilities of the managing

entity and for removing or replacing it.

(7) A description of any right to make any additions,

substitutions, or deletions of accommodations, amenities, or

component sites, and a description of the basis upon which

accommodations, amenities, or component sites may be added to,

substituted in, or deleted from the multisite time-share plan.

(8) A description of the purchaser's liability for any fees

associated with the multisite time-share plan.

(9) The location of each component site of the multisite

time-share plan, the historical occupancy of each component site for

the prior 12-month period, if the component site was part of the

multisite time-share plan during the 12-month time period, as well as

any periodic adjustment or amendment to the reservation system that

may be needed in order to respond to actual purchaser use patterns

and changes in purchaser use demand for the accommodations existing

at that time within the multisite time-share plan.

(10) Any other information that the developer, with the approval

of the commissioner, desires to include in the time-share disclosure

statement.

(c) Public reports for nonspecific time-share interest multisite

time-share plans shall include the following:

(1) The name and address of the developer.

(2) A description of the type of interest and usage rights the

purchaser will receive.

(3) A description of the duration and operation of the time-share

plan.

(4) A description of the type of insurance coverage provided for

each component site.

(5) An explanation of who holds title to the accommodations of

each component site.

(6) A description of each component site, including the name and

address of each component site.

(7) The number of accommodations and time-share interests,

expressed in periods of seven-day use availability or other time

increments applicable to the multisite time-share plan for each

component site committed to the multisite time-share plan and

available for use by purchasers and a representation about the

percentage of useable time authorized for sale, and if that

percentage is 100 percent, then a statement describing how adequate

periods of time for maintenance and repair will be provided.

(8) Each type of accommodation in terms of the number of bedrooms,

bathrooms, and sleeping capacity, and a statement of whether or not

the accommodation contains a full kitchen. For purposes of this

description, a "full kitchen" means a kitchen having a minimum of a

dishwasher, range, sink, oven, and refrigerator.

(9) A description of amenities available for use by the purchaser

at each component site.

(10) A description of any incomplete amenities at any of the

component sites along with a statement as to any assurance for

completion and the estimated date the amenities will be available.

(11) The location of each component site of the multisite

time-share plan, the historical occupancy of each component site for

the prior 12-month period, if the component site was part of the

multisite time-share plan during such 12-month time period, as well

as any periodic adjustment or amendment to the reservation system

that may be needed in order to respond to actual purchaser use

patterns and changes in purchaser use demand for the accommodations

existing at that time within the multisite time-share plan.

(12) A description of any right to make any additions,

substitutions, or deletions of accommodations, amenities, or

component sites, and a description of the basis upon which

accommodations, amenities, or component sites may be added to,

substituted in, or deleted from the multisite time-share plan.

(13) A description of the reservation system that shall include

all of the following:

(A) The entity responsible for operating the reservation system,

its relationship to the developer, and the duration of any agreement

for operation of the reservation system.

(B) A summary of the rules and regulations governing access to and

use of the reservation system.

(C) The existence of and an explanation regarding any priority

reservation features that affect a purchaser's ability to make

reservations for the use of a given accommodation on a

first-come-first-served basis.

(14) A description of any liens, defects, or encumbrances that

materially affect the purchaser's use rights.

(15) The name and principal address of the managing entity for the

multisite time-share plan and a description of the procedures, if

any, for altering the powers and responsibilities of the managing

entity and for removing or replacing it, and a description of the

relationship between a multisite time-share plan managing entity and

the managing entity of the component sites of a multisite time-share

plan, if different from the multisite time-share plan managing

entity.

(16) The current annual budget as provided in Section 11240, along

with the projected assessments and a description of the method for

calculating and apportioning the assessments among purchasers, all of

which shall be attached as an exhibit to the public report.

(17) Any current fees or charges to be paid by time-share

purchasers for the use of any amenities related to the time-share

plan and a statement that the fees or charges are subject to change.

 

(18) Any initial or special fee due from the purchaser at closing,

together with a description of the purpose and method of calculating

the fee.

(19) A description of any financing offered by or available

through the developer.

(20) A description of any bankruptcies, pending civil or criminal

suits, adjudications, or disciplinary actions of which the developer

has knowledge, which would have a material effect on the developer's

ability to perform its obligations.

(21) A statement disclosing any right of first refusal or other

restraint on the transfer of all or any portion of a time-share

interest.

(22) A statement disclosing that any deposit made in connection

with the purchase of a time-share interest shall be held by an escrow

agent until expiration of any right to cancel the contract and that

any deposit shall be returned to the purchaser if he or she elects to

exercise his or her right of cancellation. Alternatively, if the

commissioner has accepted from the developer a surety bond,

irrevocable letter of credit, or other financial assurance in lieu of

placing deposits in an escrow account: (A) a statement disclosing

that the developer has provided a surety bond, irrevocable letter of

credit, or other financial assurance in an amount equal to or in

excess of the funds that would otherwise be placed in an escrow

account, (B) a description of the type of financial assurance that

has been arranged, (C) a statement that if the purchaser elects to

exercise his or her right of cancellation as provided in the

contract, the developer shall return the deposit, and (D) a

description of the person or entity to whom the purchaser should

apply for payment.

(23) If the time-share plan provides purchasers with the

opportunity to participate in an exchange program, a description of

the name and address of the exchange company and the method by which

a purchaser accesses the exchange program.

(24) Any other information that the developer, with the approval

of the commissioner, desires to include in the time-share disclosure

statement.

(d) The commissioner may establish by regulation provisions

regarding the delivery of the public report and other required

information through alternative media forms.

(e) The commissioner may, upon finding that the subject matter is

otherwise adequately covered or the information is unnecessary or

inapplicable, waive any requirement set forth in this section.

11235. (a) A person who has entered into a contract to purchase a

short-term product shall have the right to rescind the contract

until midnight of the seventh calendar day, or a later time as

provided in the contract, following the day on which the contract is

first made, in which event the purchaser shall be entitled to a

refund of 100 percent of the consideration paid under the contract,

without deduction.

(b) The developer or other person who offers a short-term product

shall clearly and conspicuously disclose, in writing, to all

purchasers of a short-term product, all of the following:

(1) The right of rescission provided for in subdivision (a).

(2) That reservations for accommodations under the contract are

subject to availability and that there is no guarantee that a

purchaser will be able to obtain specific accommodations during a

specific time period, if applicable.

(3) Specific blackout dates, if applicable.

(4) That the earlier the purchaser requests a reservation, the

greater the opportunity to received a confirmed reservation.

(5) That, if the purchaser later purchases a time-share interest,

the developer shall provide the purchaser with the then-current

public report for the time-share plan being purchased and that the

purchaser shall have until midnight of the seventh calendar day

following receipt of the public report to cancel the purchase of the

time-share interest.

(c) If a purchaser is unable to obtain a confirmed reservation for

a specific accommodation and time period requested, the developer or

other person who offers the short-term product shall attempt to

provide the purchaser with a substantially similar alternative to the

reservation requested. If the developer or other person who offers

the short-term product is unable to provide the reservation requested

or an acceptable alternative during the initial term of the

contract, the purchaser may request and be granted an extension of

the contract for a period of 12 months.

(d) The contract for the purchase of a short-term product shall

include the date of the contract and shall contain, in immediate

proximity to the space reserved for the signature of the purchaser, a

conspicuous statement as follows:

"YOU HAVE THE RIGHT TO CANCEL THIS CONTRACT AT ANY TIME PRIOR TO

MIDNIGHT OF THE SEVENTH (7TH) (or later) CALENDAR DAY AFTER THE DATE

OF THIS CONTRACT AND RECEIVE A FULL REFUND. YOU MAY EXERCISE YOUR

RIGHT TO CANCEL BY SENDING A FACSIMILE, OR BY DEPOSIT, FIRST-CLASS

POSTAGE PREPAID, INTO THE UNITED STATES MAIL TO THE FOLLOWING

ADDRESS: (SPECIFIC CONTACT INFORMATION)"

 

(e) A purchaser of a short-term product may exercise the right of

rescission by giving written notice to the owner of the short-term

product as specified in subdivision (b), using a preprinted form

provided by the developer. The developer or other person who offers

the short-term product shall cause any deposit given by a purchaser

who has exercised the right to rescind described in subdivision (a)

to be returned to the purchaser not later than the last to occur of

10 business days following receipt of the purchaser's written notice

of rescission, or 10 business days following the date upon which any

deposit becomes good and immediately available funds.

(f) A developer or other person who offers a short-term product

shall do one of the following:

(1) Place any purchase money funds received from the purchaser of

a short-term product into an independent escrow depository until the

seven-day period for rescission described in subdivision (a) has

expired.

(2) Post a bond to secure the return of a purchaser's purchase

money funds in a form and in an amount prescribed by the

commissioner.

(3) Make alternative arrangements satisfactory to the commissioner

to secure the owner's obligation to return the purchase money funds.

 

(g) If applicable, the developer shall disclose to the purchaser

the type of alternative arrangement to be used and, in the event of a

claim, to whom the purchaser should apply for payment under the

alternative arrangement.

(h) The developer shall compensate the association for any

services acquired from the association or for any of the association'

s property used when fulfilling a short-term product in excess of

services or use of property provided to other owners.

(i) If the contract for a short-term product is negotiated

primarily in Spanish, Chinese, Tagalog, Vietnamese, or Korean, orally

or in writing, the developer shall provide to the prospective

purchaser prior to the commencement of the rescission period an

unexecuted translation of the contract in the language in which the

contract was negotiated. The terms of the short-term contract that

is executed in the English language shall determine the rights and

obligations of the parties.

11236. (a) A receipt on the form specified herein shall be taken

by or on behalf of the developer from each person executing a

reservation agreement under authority of a preliminary public report

and each person who has made a written offer to purchase or lease a

time-share interest under authority of a preliminary, conditional, or

final public report.

(b) The developer or his or her agent shall retain each receipt

for a final public report for a period of three years from the date

of the receipt and shall make the receipts available for inspection

by the commissioner or his or her designated representative during

regular business hours.

(c) The form approved by the commissioner for the acknowledgment

of receipt of a preliminary, conditional, or final public report

shall be as follows:

"RECEIPT FOR PUBLIC REPORT

The Law and Regulations of the commissioner require that you as

a prospective purchaser or lessee be afforded an opportunity to read

the public report for this time-share before you execute a contract

to purchase or lease a time-share interest or before any money or

other consideration toward purchase or lease of a time-share interest

is accepted from you.

You must be afforded an opportunity to read the report before a

written reservation or any deposit in connection therewith is

accepted from you.

DO NOT SIGN THIS RECEIPT UNTIL YOU HAVE RECEIVED A COPY OF THE

REPORT AND HAVE READ IT.

I have read the commissioner's public report on ____ (File No.,

Tract No., or Name). I understand the report is not a recommendation

or endorsement of the time-share, but is for information only. The

date of the public report which I received and read is ____.

Developer Is Required to Retain This Receipt for Three Years.

 

11237. (a) If a purchaser of a time-share interest in a

time-share plan is offered the opportunity to acquire an incidental

benefit in connection with the sale of a time-share interest, the

developer shall provide the purchaser with a disclosure statement

containing all of the following information:

(1) A general description of the incidental benefit, including the

terms and conditions governing the use of the incidental benefit.

(2) A statement that the continued availability of the incidental

benefit is not necessary for the use and enjoyment of the purchaser's

use of any accommodation of the time-share plan.

(3) A statement that the purchaser's use of or participation in

the incidental benefit is completely voluntary, and payment of any

fee or other cost associated with the incidental benefit is required

only upon that use or participation.

(4) A listing of the fees, if any, that the purchaser will be

required to pay to use the incidental benefit.

(5) A statement that no costs of acquisition, operation,

maintenance, or repair of the incidental benefit shall be passed on

to purchasers of time-share interests in the time-share plan as a

common expense of the time-share plan.

(b) A developer shall include in its initial application for

registration, a description of any incidental benefits which may be

used by the developer. The developer may, but shall not be required

to describe the incidental benefits in the public report for the

time-share plan.

(c) The incidental benefit disclosure is not required to be filed

with the commissioner prior to the use of the disclosure. However,

the commissioner may request and review the records of the developer

to ensure that the incidental benefit disclosure required by this

section has been given to purchasers and to ensure that the

statements required to be made in the disclosure are accurate as to

the operation of each incidental benefit offered by the developer.

The developer shall deliver the records to the commissioner within 10

business days of the commissioner's request.

11238. (a) The purchase contract entered into by any person who

has made an offer to purchase a time-share interest or interests, any

incidental benefit, made on the same day or within seven calendar

days after the person attended a sales presentation for a time-share

interest, or any right under an exchange program, made on the same

day or within seven calendar days after the person attended a sales

presentation for a time-share interest, shall be voidable by the

purchaser, without penalty, within seven calendar days, or a longer

period as provided in the contract, after the receipt of the public

report or the execution of the purchase contract, whichever is later.

 

(1) The purchase contract shall provide notice of the seven-day

cancellation period, together with the name and mailing address to

which any notice of cancellation shall be delivered.

(2) Notice of cancellation shall be deemed timely if given not

later than midnight of the seventh calendar day.

(b) A person who has made an offer to purchase a time-share

interest, incidental benefit, or rights under an exchange program as

described above may exercise the right of cancellation granted by

this section by giving written notification of the notice to cancel

to the developer at the place of business designated by the developer

in the purchase contract.

(c) If the notice of cancellation is by United States mail, a

rebuttable presumption shall exist that notice was given on the date

that it is postmarked. If the notice is sent by facsimile, it shall

be considered given on the date of a confirmed transmission. If the

notice is by means of a writing sent other than by United States mail

or telegraph, it shall be considered as given at the time of

delivery at the place of business designated by the developer.

Exercising the rescission rights of the time-share interest shall

also automatically rescind any agreement for the purchase of an

incidental benefit or an enrollment into an exchange program where

the agreements were entered into in conjunction with the purchase of

the time-share interest.

(d) Each developer shall utilize and furnish each purchaser with a

fully completed and executed copy of a contract pertaining to the

sale of a time-share interest, which contract shall include the

following information:

(1) The actual date the contract is executed by each party.

(2) The names and addresses of the developer and time-share plan.

 

(3) The initial purchase price and any additional charges to which

the purchaser may be subject to in connection with the purchase of

the time-share interest, including, but not limited to, financing, or

other amounts that will be collected from the purchaser on or before

closing, such as the current year's annual assessment for common

expenses.

(4) The estimated date of completion of construction of each

accommodation promised to be completed which is not completed at the

time the contract is executed.

(5) A brief description of the nature and duration of the

time-share interest being sold, including whether any interest in

real property is being conveyed.

(6) The specific number of years of the term of the time-share

plan.

(7) Immediately prior to the space reserved in the contract for

the signature of the purchaser, the developer shall disclose, in

conspicuous type, substantially the following notice of cancellation:

You may cancel this contract without any penalty or obligation

within seven calendar days of receipt of the public report or after

the date you sign this contract, whichever date is later. If you

decide to cancel this contract, you must notify the developer in

writing of your intent to cancel. Your notice of cancellation shall

be effective upon the date sent and shall be sent to (name of

developer) at (address of developer). Your notice of cancellation

may also be sent by facsimile to (facsimile number of the developer)

or by hand-delivery. Any attempt to obtain a waiver of your

cancellation right is void and of no effect.

 

(8) The purchase contract for an interest in a single site or

specific time-share interest multisite time-share plan without an

accommodation in this state shall include the following additional

disclosure in conspicuous type:

The accommodations of this time-share plan are located outside of

California. As such, the management (including all matters relating

to the association, the association budget, and any management

contract) of this time-share plan is not governed by California law,

but by the applicable law, if any, of the jurisdiction in which the

accommodations are located as stated in the public report. You

should review the governing documents related to the association, the

association's budget, and the management of the time-share plan.

 

(e) If rescission is sought and granted for a violation of this

section, the court may also award reasonable attorneys' fees and

costs to the prevailing purchaser.

11239. (a) To inform a purchaser of his or her right of

cancellation under Section 11238, the developer shall attach to the

face page of every copy of a public report given to a prospective

purchaser, the cancellation notice set forth in subdivision (b)

thereof printed in conspicuous type.

(b) The form and content of the notice shall be as follows:

 

NOTICE OF CANCELLATION RIGHTS

You may cancel the purchase of the time-share interest(s) in the

time-share plan identified below without any penalty or obligation

and are legally entitled to the return of all money and other

considerations that you have given toward the purchase. If you

decide to cancel your purchase, you must notify the developer in

writing of your intent to cancel within seven calendar days of

receipt of the public report or the date you sign the purchase

contract, whichever date is later. Your notice of cancellation shall

be effective upon the date sent and shall be sent to the developer

at the address or facsimile number provided in your purchase

contract. Any attempt to obtain a waiver of your cancellation right

is void and of no effect.

 

(c) Each notice shall also contain the following form. The form

shall have all developer-related information completed by the

developer and may be used by a purchaser to cancel the sale of the

time- share interest:

(Name of Developer) (Address of Developer) (Facsimile Number of

Developer) (Name of Time-share Plan) (DRE Registration File Number)

RE: ELECTION TO CANCEL THE SALE OF A TIME-SHARE INTEREST(S) I hereby

elect to cancel my purchase of the time-share interest(s) in the

above-name time-share plan.

 

 

 

_______________________________

(Date)

_______________________________ ______________________________

(Signature) (Print Name)

_______________________________ ______________________________

(Signature) (Print Name)

 

11240. An estimated operating budget for the time-share plan

shall be filed with the commissioner along with the other information

required to be registered pursuant to this chapter, and shall

contain the following information:

(a) The estimated annual expenses of the time-share plan along

with the estimated revenue of the association from all sources,

including the amounts collectible from purchasers as assessments.

The estimated payments by the purchaser for assessments shall also be

stated in the estimated amounts for the times when they will be due.

Expenses shall be shown in a manner that enables the purchaser to

calculate the annual expenses associated with the time-share interest

being purchased. Expenses that are personal to purchasers that are

not uniformly incurred by all purchasers or that are not provided for

or contemplated by the time-share plan documents may be excluded

from this estimate.

(b) (1) The estimated items of expenses of the time-share plan and

the association, except as excluded under subdivision (a),

including, but not limited to, if applicable, the following items,

that shall be stated either as association expenses collectible by

assessments or as expenses of the purchaser payable to persons other

than the association:

(2) Expenses for the association:

(A) Administration of the association.

(B) Management fees.

(C) Maintenance.

(D) Rent for accommodations.

(E) Taxes upon time-share property.

(F) Taxes upon leased areas.

(G) Insurance.

(H) Security provisions.

(I) Other expenses.

(J) Operating capital.

(K) Equitable apportionment of expenses between time-share and

non-time-share uses of the common area, if applicable.

(L) Reserves for deferred maintenance and reserves for capital

expenditures. All reserves for any accommodations and common areas

of a time-share plan located in this state shall be based upon the

estimated life and replacement cost of accommodations and common

elements of the time-share plan. For any accommodations and common

elements of a time-share plan located outside of this state, the

developer shall disclose the amount of reserves for deferred

maintenance and capital expenditures required by the law of the situs

state, if applicable, and maintained for those accommodations and

common elements, which amount of reserves shall be based on the

estimated life and replacement cost of each reserve item. The

developer or the association shall include in the budget a reasonable

reserve accumulation plan. A plan that (i) provides for reserves to

be funded within five years at a level of 50 percent of the amount

specified in the reserve study as fully funded, and (ii) requires

those reserves collected in any given year to equal or exceed the

amount of reserve expenditures estimated for that year shall be

deemed to be a reasonable reserve accumulation plan. The funding of

reserves may be based on collection of reserve amounts in conjunction

with annual assessments, or on some alternative mechanism,

including, but not limited to, a bond, letter of credit, or similar

mechanism. Collection of required reserve amounts solely by one or

more special assessments is not reasonable. If control of the

association is in owners other than the developer, and such owners

vote not to maintain reserves or to maintain reserves at less than 50

percent, the failure to maintain the required level of reserves

shall not be cause for denying the developer a public report.

(c) The estimated amounts shall be stated for a period of at least

12 months and may distinguish between the period prior to the time

that purchasers elect a majority of the board of administration and

the period after that date.

(d) The budget of a phase time-share plan shall contain a note

identifying the number of time-share interests covered by the budget,

indicating the number of time-share interests, if any, estimated to

be declared as part of the time-share plan during that calendar year,

and projecting the common expenses for the time-share plan based

upon the number of time-share interests estimated to be declared as

part of the time-share plan during that calendar year.

(e) For single site time-share plans and component sites of a

multisite time-share plan located outside of the state, the budget

shall include the subject matter set forth in subdivisions (a) to

(d), inclusive. The budget shall be in compliance with the

applicable laws of the state or jurisdiction in which the time-share

property or component site is located, and if there is a conflict

between the affirmative standards set forth in the laws of the situs

state and the requirements set forth in this section, the law of the

situs state shall control. If the budget provides for the matters

contained in subdivisions (a) to (d), inclusive, the budget shall be

deemed to be in compliance with the requirements of this section, and

the developer shall not be required to make revisions in order to

comply with this section.

(f) The budget shall include a certification subscribed and sworn

by an expert in the preparation of time-share plan budgets, who may

be (1) an independent public accountant, (2) a certified public

accountant, who is an employee of the developer, or (3) at the

discretion of the commissioner, another qualified individual or

entity. If the budget certification is prepared by a certified public

accountant who is an employee of the developer who is not the chief

financial officer, the certification shall also be signed on behalf

of the developer by an appropriate officer, if the developer is a

corporation, or the managing member, if the developer is a limited

liability company. The certification concerning the adequacy of the

budget shall be in the following form:

On behalf of the developer of the captioned time-share plan, I/my

firm has reviewed or prepared the budget containing projections of

income and expenses for time-share operation. My/our experience in

this field includes:

I/we have reviewed the budget and investigated the facts set forth

in the budget and the facts underlying it with due diligence in order

to form a basis for this certification.

I/we certify that the projections in the budget appear reasonable

and adequate based on present prices (adjusted to reflect continued

inflation and present levels of consumption for comparable units

similarly situated) or, for an existing project, based on historical

data for the project.

I/we certify that the budget:

(1) Sets forth in detail the terms of the transaction as it relates

to the budget and is complete, current, and accurate. (2) Affords

potential investors, purchasers, and participants an adequate basis

upon which to found their judgment. (3) Does not omit any material

fact. (4) Does not contain any untrue statement of a material fact.

(5) Does not contain any fraud, deception, concealment, or

suppression. (6) Does not contain any promise or representation as

to the future which is beyond reasonable expectation or unwarranted

by existing circumstances. (7) Does not contain any representation

or statement which is false, where I/we:

(A) Knew the truth. (B) With reasonable effort could have known

the truth. (C) Made no reasonable effort to ascertain the truth.

(D) Did not have knowledge concerning the representation or statement

made.

I/we understand that a copy of this certification is intended to be

incorporated into the public report so that prospective purchasers

may rely on it.

This certification is made under the penalty of perjury for the

benefit of all persons to whom this offer is made. We understand

that violations are subject to the civil and criminal penalties of

the laws of California.

The certification shall be dated within 90 days prior to the date

of the submission of the budget to the commissioner. The expert's

certification shall be based on experience in the management of

hotel, resort, or time-share properties and disclose the approximate

number of properties managed and length of time managed, together

with other relevant real estate experience, qualifications, and

licenses.

 

(g) Any budget that is not certified by an independent certified

public accountant or an employee of the developer who is licensed as

a certified public accountant may be reviewed by the commissioner to

confirm the accuracy of the certification.

(h) The certified budget for the time-share plan shall be prepared

and submitted by the developer to the commissioner annually for as

long as the registration is in effect. If the budget is increased

more than 20 percent in any year, the developer shall submit to the

commissioner, along with the increased budget, evidence that the

requirements of paragraph (5) of subdivision (a) of Section 11265

have been met. The budget shall be submitted at least 15 days prior

to the first day of the period that it covers. Upon the submission

of each annual budget, the exhibit to the public report specified in

paragraph (8) of subdivision (a) of, and paragraph (16) of

subdivision (c) of, Section 11234 shall be updated. The updating of

the exhibit shall not be considered to constitute an amendment of the

public report.

(i) The audited financial statements of the association prepared

pursuant to paragraph (2) of subdivision (b) of Section 11272 shall

be delivered to the commissioner upon request.

(j) At the time an application is submitted for renewal of the

public report or any amendment of the public report that affects the

budget for the time-share plan, the developer shall submit with the

application a copy of the most recent audited financial statement for

the time-share plan, along with a certified copy of the budget

reflecting the amendment or renewal. If the commissioner, upon

reasonable comparison of the budget and the prior year's audited

financial statements, determines that the budget is deficient, the

commissioner may subject the budget to a substantive review.

11241. (a) The developer is obligated for the expenses associated

with unsold inventory held by the developer. The obligation can be

fulfilled in either of the following ways:

(1) The developer shall pay the full maintenance fee for each of

the interests owned by the developer.

(2) The developer shall enter into a subsidy agreement with the

association to subsidize the association budget by covering any

shortfall from expenses incurred and assessments collected from other

owners.

(b) To assure the fulfillment of the obligations of the developer

of a time-share plan to either pay assessments as an owner of

time-share interests in the time-share plan or to pay a subsidy, the

commissioner shall require that the developer furnish a surety bond,

cash deposit, letter of credit, or other alternate assurance

enforceable by the association and acceptable to the commissioner and

that assurance shall be in the amount required by subdivision (c)

and shall be in compliance with either paragraph (1) or (2) of

subdivision (c).

(c) The amount of the assurance shall be equal to the lesser of 50

percent of the anticipated cost of operation and maintenance of the

time-share plan, including the establishment of reserves for

replacement and major repair, for an operational period of one year

or 100 percent of the assessments attributed to the total amount of

the total unsold time-share interests owned by the developer and

registered pursuant to this chapter. The security shall be delivered

to a neutral escrow depository, or to the trustee if title to the

time-share property has been delivered to the trustee, along with

instructions signed by the developer for the benefit of the

association which shall provide as follows:

(1) Where the developer pays full maintenance fees on unsold

inventory the security shall remain available to pay any assessments

for which the developer is liable and delinquent until the depository

or trustee has received both of the following:

(A) Written notice, from the developer that sales of 80 percent of

the time-share interest in the time-share plan have been closed.

(B) Written notice from the association that the developer is not

delinquent in the payment of assessments for which it is obligated.

(2) Where the developer subsidizes the association in lieu of

paying full maintenance fees, the developer shall enter into a

subsidy agreement in accordance with the provisions of Section 11242.

 

(d) If there is a dispute between the developer and the

association with respect to the question of satisfaction of the

conditions for exoneration or release of the security, the issue

shall, at the request of either party, be submitted to arbitration in

accordance with the Commercial Arbitration Rules of the American

Arbitration Association. The fee payable to the American Arbitration

Association to initiate the arbitration shall be remitted by the

developer. The cost of arbitration shall ultimately be borne as

determined by the arbitrator under these rules.

11242. (a) In any time-share plan in which the developer

undertakes to subsidize the cost of operating and maintaining the

time-share plan, the developer shall do all of the following:

(1) Enter into a contract with the association that specifies in

detail the obligations of the developer and the methods to be used in

valuing the goods and services furnished under the time-share plan.

The department will not approve a subsidization program unless

provisions are made for the accumulation of reserves for replacement

and major maintenance of the time-share property in accordance with

accepted property management practices and the transfer of the

reserve fund to the association on termination of the program.

(2) Furnish the association with an executed copy of the

subsidization contract within 10 days after closing of escrow of the

first sale or lease of a time-share interest.

(3) Furnish the assurance required by Section 11241.

(b) The assurance specified in paragraph (3) of subdivision (a)

shall be delivered to the trustee or an escrow depository acceptable

to the department along with an executed copy of the subsidization

contract and instructions to the escrow signed by the developer and

on behalf of the association. The instructions shall provide for

both of the following:

(1) The escrow agent shall not release or exonerate the security

device until it has received written notice, from the association

that the developer has faithfully performed all of his or her

obligations under the subsidization contract.

(2) If there is a dispute between the developer and the

association with respect to the questions of satisfaction of the

conditions for exoneration or release of the security, the issue or

issues shall, at the request of either party, be submitted to

arbitration in accordance with the Commercial Arbitration Rules of

the American Arbitration Association.

(c) The fee payable to the American Arbitration Association to

initiate arbitration shall be submitted by the developer. The costs

of arbitration shall be borne by the party as determined by the

arbitrator pursuant to the rules specified in paragraph (2) of

subdivision (b).

11243. The developer shall comply with the following escrow

requirements:

(a) A developer of a time-share plan shall deposit into an escrow

account in an acceptable escrow depository 100 percent of all funds

that are received during the purchaser's rescission period. An

acceptable escrow depository includes, when qualified to do business

in this state, escrow agents licensed by the Commissioner of

Corporations, banks, trust companies, savings and loan associations,

title insurers, and underwritten title companies. The deposit of

these funds shall be evidenced by an executed escrow agreement

between the escrow agent and the developer, that shall include

provisions that state the following:

(1) Funds may be disbursed to the developer by the escrow agent

from the escrow account only after expiration of the purchaser's

rescission period and in accordance with the purchase contract,

subject to subdivision (b).

(2) If a prospective purchaser properly cancels the purchase

contract pursuant to its terms, the funds shall be paid to the

prospective purchaser or paid to the developer if the prospective

purchaser's funds have been previously refunded by the developer.

(b) If a developer contracts to sell a time-share interest and the

construction of any property in which the time-share interest is

located has not been completed, the developer, upon expiration of the

rescission period, shall continue to maintain in an escrow account

all funds received by or on behalf of the developer from the

prospective purchaser under his or her purchase contract. The

commissioner shall establish, by regulation, the types of

documentation which shall be required for evidence of completion,

including, but not limited to, a certificate of occupancy, a

certificate of substantial completion, or an inspection by the State

Fire Marshal designee or an equivalent public safety inspection

agency in the applicable jurisdiction. Unless the developer submits

financial assurances, in accordance with subdivision (c), funds shall

not be released from escrow until a certificate of occupancy, or its

equivalent, has been obtained and the rescission period has passed,

and the time-share interest can be transferred free and clear of

blanket encumbrances, including mechanics' liens. Funds to be

released from escrow shall be released as follows:

(1) If a prospective purchaser properly cancels the purchase

contract pursuant to its terms, the funds shall be paid to the

prospective purchaser or paid to the developer if the prospective

purchaser's funds have been previously refunded by the developer.

(2) If a prospective purchaser defaults in the performance of the

prospective purchaser's obligations under the purchase contract, the

funds shall be paid to the developer.

(3) If the funds of a prospective purchaser have not been

previously disbursed in accordance with the provisions of this

subdivision, they may be disbursed to the developer by the escrow

agent upon the issuance of acceptable evidence of completion of

construction.

(c) In lieu of the provisions in subdivisions (a) and (b), the

commissioner may accept from the developer a surety bond, escrow

bond, irrevocable letter of credit, or other financial assurance or

arrangement acceptable to the commissioner. Any acceptable financial

assurance shall be in an amount equal to or in excess of the lesser

of (1) the funds that would otherwise be placed in escrow, or (2) in

an amount equal to the cost to complete the incomplete property in

which the time-share interest is located. However, in no event shall

the amount be less than the amount of funds that would otherwise be

placed in escrow pursuant to paragraph (1) of subdivision (a).

(d) The developer shall provide escrow account information to the

commissioner and shall execute in writing an authorization consenting

to an audit or examination of the account by the commissioner on

forms provided by the commissioner. The developer shall comply with

the reconciliation and records requirements established by regulation

by the commissioner. The developer shall make documents related to

the escrow account or escrow obligation available to the commissioner

upon the department's request. The escrow agent shall maintain any

disputed funds in the escrow account until either of the following

occurs:

(1) Receipt of written direction agreed to by signature of all

parties.

(2) Deposit of the funds with a court of competent jurisdiction in

which a civil action regarding the funds has been filed.

11244. (a) Excluding any encumbrance placed against the purchaser'

s time-share interest securing the purchaser's payment of purchase

money financing for the purchase, the developer shall not be entitled

to the release of any funds escrowed under Section 11243 with

respect to each time-share interest and any other property or rights

to property appurtenant to the time-share interest, including any

amenities represented to the purchaser as being part of the

time-share plan, until the developer has provided satisfactory

evidence to the commissioner of one of the following:

(1) The time-share interest, including, but not limited to, a

time-share interest in any component sites of a nonspecific

time-share interest multisite time-share plan, together with any

other property or rights to property appurtenant to the time-share

interest, including any amenities represented to the purchaser as

being part of the time-share plan, are free and clear of any of the

claims of the developer, any owner of the underlying fee, a

mortgagee, judgment creditor, or other lienor, or any other person

having an interest in or lien or encumbrance against the time-share

interest or appurtenant property or property rights.

(2) The developer, any owner of the underlying fee, a mortgagee,

judgment creditor, or other lienor, or any other person having an

interest in or lien or encumbrance against the time-share interest or

appurtenant property or property rights, including any amenities

represented to the purchaser as being part of the time-share plan,

has recorded a subordination and notice to creditors document in the

appropriate public records of the jurisdiction in which the

time-share interest is located. The subordination document shall

expressly and effectively provide that the interest holder's right,

lien, or encumbrance shall not adversely affect, and shall be

subordinate to, the rights of the owners of the time-share interests

in the time-share plan regardless of the date of purchase, from and

after the effective date of the subordination document.

(3) The developer, any owner of the underlying fee, a mortgagee,

judgment creditor, or other lienor, or any other person having an

interest in or lien or encumbrance against the time-share interest or

appurtenant property or property rights, including any amenities

represented to the purchaser as being part of the time-share plan,

has transferred the subject accommodations, amenities, or all use

rights in the amenities to a nonprofit organization or owners'

association to be held for the use and benefit of the owners of the

time-share plan, which shall act as a fiduciary to the purchasers,

the developer has transferred control of the entity to the owners or

does not exercise its voting rights in the entity with respect to the

subject accommodations or amenities. Prior to the transfer, any

lien or other encumbrance against the accommodation or facility shall

be made subject to a subordination and notice to creditors'

instrument pursuant to paragraph (2).

(4) Alternative arrangements have been made which are adequate to

protect the rights of the purchasers of the time-share interests and

approved by the commissioner.

(b) Nothing in this section shall prevent a developer from

accessing any escrow funds if the developer has complied with

subdivision (c) of Section 11243.

(c) The developer shall notify the commissioner of the extent to

which an accommodation may become subject to a tax or other lien

arising out of claims against other purchasers in the same time-share

plan. The commissioner may require the developer to notify a

prospective purchaser of any such potential tax or lien that would

materially and adversely affect the prospective purchaser.

11245. (a) No person subject to this chapter shall do any of the

following:

(1) Make any material misrepresentation that is false or

misleading in connection with any advertisement or promotion of a

time-share plan.

(2) Make a prediction of any increases in the resale price or

resale value of the time-share interest.

(3) Materially misrepresent the size, nature, extent, qualities,

or characteristics of the offered time-share plan.

(4) Materially misrepresent the conditions under which a purchaser

may exchange the right to use accommodations in one location for the

right to use accommodations in another location.

(5) Materially misrepresent the current or future availability of

a resale or rental program offered by or on behalf of the developer.

 

(6) Materially misrepresent the nature or extent of any incidental

benefit.

(7) Fail to deliver any item offered in connection with a

promotion to a prospective purchaser upon the conclusion of the sales

presentation, or fail to deliver any item offered in connection with

a promotion to a prospective purchaser, upon request, reasonably

approximate to the conclusion of the length of time for the sales

presentation that was previously represented to the prospective

purchaser.

(8) Fail to disclose, in a manner that meets the requirements of

Section 17537.1 or 17537.2 of the Business and Professions Code, that

a certificate, coupon, or raincheck redeemable for fulfillment for

goods or services will be provided in connection with a promotion for

the purchase of a time-share interest, if that is the case.

(9) State that the purchase of a time-share interest constitutes a

financial investment.

(10) Fail to clearly and conspicuously disclose, prior to the

execution of any purchase contract, the annual maintenance and

association dues or any separately billed taxes, when applicable.

(11) Fail to clearly disclose in writing any automatic charging or

billing procedure, and fail thereafter to obtain the express written

authorization from the prospective purchaser for any purchase,

subscription, or enrollment that results in that automatic charging

or billing of initial or periodic amounts to the prospective

purchaser.

(12) If the contract for a time-share interest is negotiated

primarily in Spanish, Chinese, Tagalog, Vietnamese, or Korean, orally

or in writing, and the developer fails to provide to the prospective

purchaser prior to the commencement of the rescission period an

unexecuted translation of the contract in the language in which the

contract was negotiated.

(13) Fail to inform, verbally or in writing, any

prospective purchaser that he or she can take as much time as he or

she requires in order to read the public report, and any and all

other documents necessary to consummate a sale before leaving the

premises or signing a contract, and not allowing, upon request, the

prospective purchaser the time and opportunity to do so. If the

prospective purchaser requests that he or she be able to return the

next calendar day to complete the review of the documents before

signing, the developer shall accommodate such a request, and the

return visit shall not disqualify the prospective purchaser from

receiving any price reduction or other incentive for purchasing on

the day of the scheduled sales presentation. Further, it shall not

be fraudulent or misleading for a developer to honor the request even

if presented as an incentive only available on the day of the offer.

 

(14) Inform prospective purchasers that they are finalists in

winning an item offered in connection with a promotion or have

already won a specific prize, unless it is true.

(15) Offer as a promotional incentive any travel certificate or

coupon redeemable for transportation, accommodations, or other

travel-related service that does not allow the recipient to activate

or redeem the incentive without incurring any additional telephone

expenses charged by or on behalf of the developer other than the

usual toll costs imposed by the prospective purchaser's telephone

service.

(16) Offer as a promotional incentive any travel certificate or

coupon redeemable for fixed air transportation or hotel

accommodations or other travel-related service that entitles the

prospective purchaser to a trip of a specified duration unless the

offeror states at the time of the offer that there are terms or

conditions that must be followed in order to utilize the incentive

and that the details of the terms will be sent to the consumer in

writing in time to be received by the consumer prior to leaving his

or her house to attend the scheduled sales presentation. The writing

shall include the approximate times of the air or sea transportation'

s departure and return, if applicable, and all other material

conditions, including any limitations as to the dates or times

available for use of the incentive.

(17) Misrepresent or fail to disclose that a prospective purchaser

is required to attend a sales presentation to obtain a prize or

promotional item, if attendance is a requirement of the promotion.

(18) Fail to inform any prospective purchaser who contacts the

developer with a request to cancel a purchase within the rescission

period provided by this chapter all of the procedures necessary to

effectively cancel the purchase.

(19) Fail to cancel a purchase upon the receipt of a valid timely

written notice of rescission. No person may obtain from the person a

waiver or cancellation of the rescission.

(20) Fail to provide any refund of moneys, within the required

timeframe, due to the prospective purchaser upon receipt of a valid

timely written notice of rescission.

(21) Fail to provide a mechanism for an equitable apportionment of

expenses between the time-share owner's association and any

commercial operation on the property not operated by the time-share

owner's association.

(b) For any time-share plan in which the managing entity is an

affiliate of the developer, neither the developer nor the managing

entity shall, during any applicable priority reservation period, hold

out for rental to the public on a given day, developer owned or

controlled time-share periods in a number greater than the total

number of time-share periods owned or controlled by the developer in

a particular season, multiplied by a fraction wherein the numerator

is the number of time-share periods owned or controlled by the

developer in that particular season, and the denominator is the total

number or time-share periods in that particular season. For

example, if the developer owns or controls 1,000 time-share periods

in a particular season, out of a total of 4,000 time-share periods

available during that season, then the developer may not hold out for

rental to the public during any applicable priority reservation

period, more than 250 time-share periods on a given day during that

season (1,000 X 1,000/4,000=250). The number of time-share interests

permitted to be rented under this subdivision shall be in addition

to any time-share interests that the developer may have the right to

rent or use by virtue of having acquired those rights from another

owner. The developer or managing entity may, at any time, rent any

inventory transferred to the developer or managing entity by another

owner in exchange for hotel accommodations, future use rights, or

other considerations. For any use or rental by a developer of

time-share interests owned or controlled by the developer, the

developer shall reimburse the association for any increased expenses

for housekeeping services that exceed the amount allocated in the

assessment for maintenance for the use or rental.

11246. With each application for an amendment or renewal of a

public report, and with the initial submittal of an application for a

time-share plan in which sales have occurred prior to obtaining a

California public report, the developer shall submit to the

commissioner a certification by an independent third party acceptable

to the commissioner and dated not more than three months prior to

the submittal of the application, stating that the inventory control

system, described in paragraph (6) of subdivision (c) of Section

11226 functions in accordance with the description set forth in that

section. The certification shall be based on a random sampling of

transactions performed within the six months preceding the date of

the application. Inventory control systems that cover time-share

estates for which the developer offers, and the title insurance

company agrees to provide title insurance, shall not require

certification. Independent title insurance companies licensed to do

business as such in this state and independent certified public

accountants shall be deemed acceptable third parties in accordance

with this section.

 

Article 3. Time-Share Plan Requirements

 

11250. A time-share plan may be created in any accommodation

unless otherwise prohibited. All time-share plans shall maintain a

one-to-one purchaser to accommodation ratio, which means the ratio of

the number of purchasers eligible to use the accommodations of a

time-share plan on a given night to the number of accommodations

available for use within the plan on that night, such that the total

number of purchasers eligible to use the accommodations of the

time-share plan during a given calendar year never exceeds the total

number of accommodations available for use in the time-share plan

during that year. For purposes of the calculation under this

section, each purchaser must be counted at least once, and no

individual accommodation may be counted more than 365 times per

calendar year or more than 366 times per leap year. A purchaser who

is delinquent in the payment of time-share plan assessments shall

continue to be considered eligible to use the accommodations of the

time-share plan for purposes of calculating the one-to-one purchaser

to accommodation ratio.

11251. (a) The developer of a single site time-share plan and for

the component sites of a multisite time-share plan located in the

state, shall cause to be recorded prior to the closing of the first

sale of a time-share interest in each accommodation in the time-share

plan, covenants dedicating the accommodations to the time-share plan

and incorporating all covenants of the grantor or lessor of the

time-share interests, and the following provisions:

(1) Organization of an association of time-share interest owners.

 

(2) A description of the real property for the common ownership or

use of the time-share interest owners. Where the time-share plan is

a personal property time-share plan, a description of the personal

property for common use of the time-share interest owners.

(3) A description of the method for calculating and collecting

regular and special assessments from time-share interest owners to

defray expenses of the time-share property and for related purposes.

 

(4) A description of the method for terminating the membership and

selling the interest of a time-share interest owner for failure to

pay regular or special assessments.

(5) A description of the method for the disciplining of time-share

interest owners for the late payment of assessments.

(6) Provisions requiring comprehensive general liability insurance

and adequate property and casualty insurance covering the time-share

property.

(7) Restrictions upon partition of an accommodation of the

time-share plan.

(8) A description of the method for amending the covenants

affecting the time-share plan.

(9) Where applicable, a description of the method relating to the

annexation or de-annexation of additional accommodations, phases, or

properties to the time-share plan.

(10) A description of the procedures in the event of condemnation,

destruction, or extensive damage to an accommodation, including

provisions for the disposition of insurance proceeds or damages

payable on account of damage or condemnation.

(11) A method of the procedures on regular termination of the

time-share plan.

(12) Where applicable, allocation of the cost of maintenance and

operation between different elements or mixed uses within the

portions of a project or relating to reciprocal rights and

obligations between the time-share project and other property.

(13) A description of the method for entry into accommodations of

the time-share plan under authority granted by the association for

the purpose of cleaning, maid service, maintenance, and repair

including emergency repairs and for the purpose of abating a nuisance

or a known or suspected dangerous or unlawful activity.

(14) Delineate all reserved rights of the developer.

(15) For projects located within the state, the covenants shall,

insofar as reasonably possible, satisfy the requirements of Section

1468 or Sections 1469 and 1470 of the Civil Code for real property

located in this state.

(b) For single site time-share plans and component sites of a

multisite time-share plan located outside of the state, the developer

shall cause to be recorded a declaration dedicating the

accommodations to the time-share plan and incorporating all covenants

of the grantor or lessor of the time-share interests. The

declaration shall include the subject matter set forth in paragraphs

(1) to (14), inclusive, of subdivision (a). If there is no provision

for the recording of a declaration in the state or jurisdiction in

which the time-share property or component site is located,

alternatively, the developer shall establish that the declaration is

otherwise enforceable in the state or jurisdiction in which the

time-share property or component site is located. The declaration

shall be in compliance with the applicable laws of the state or

jurisdiction in which the time-share property or component site is

located, and if a conflict exists between laws of the situs state and

the requirements set forth in this section, the law of the situs

state shall control. If the declaration provides for the matters

contained in paragraphs (1) to (14), inclusive, of subdivision (a),

the declaration shall be deemed to be in compliance with the

requirements of subdivision (a) and this subdivision and the

developer shall not be required to make revisions in order to comply

with subdivision (a) and this subdivision.

(c) The developer of a time-share plan located within the state

shall make provisions in the time-share instruments for all of the

following:

(1) A description of the services to be made available to

time-share interest owners under the time-share plan.

(2) A description, to be contained in the declaration or the

bylaws of the association, of the procedures regarding transfer to

the association of control over the time-share property and services

comprising the time-share plan.

(3) A description of the method for preparation and availability

to time-share interest owners of budgets, financial statements, and

other information related to the time-share plan.

(4) A description of the methods for employing and for terminating

the employment of a managing entity for the time-share plan.

(5) A description of the method for adoption of standards and

rules of conduct for the use of accommodations by time-share interest

owners.

(6) A description of the method for establishment of the rights of

time-share interest owners to the use of an accommodation according

to schedule or under a first-reserved, first-served priority system.

 

(7) A description of the method for compensating use periods or

monetary compensation for an owner of a time-share estate if an

accommodation cannot be made available for the period of use to which

the owner is entitled by schedule or under a reservation system

because of an error by the association or managing entity.

(8) A description of the method for the use of accommodations for

transient accommodations or other income-producing purpose during

periods of nonuse by time-share interest owners.

(9) A description of the method for the inspection of the books

and records of the association by time-share interest owners.

(10) A description of the method for collective decisionmaking and

the undertaking of action by or in the name of the association

including, where applicable, representation of time-share

accommodations in an association for the time-share in which the

accommodations are located.

(d) For single site time-share plans and component sites of a

multisite time-share plan located outside of the state, the developer

shall cause to be included in the time-share instrument the subject

matter set forth in subdivision (c). The time-share instruments

shall be in compliance with the applicable laws of the state or

jurisdiction in which the time-share property or component site is

located, and if there is a conflict between laws of the situs state

and the requirements set forth in this section, the law of the situs

state shall control. If the time-share instruments provide for the

matters contained in subdivision (c), the time-share instruments

shall be deemed to be in compliance with the requirements of

subdivision (c) and this subdivision and the developer shall not be

required to make revisions in order to comply with subdivision (c)

and this subdivision.

11252. In a time-share plan offering time-share use interests,

the developer shall not encumber the accommodations of the time-share

plan in a manner that could materially and adversely affect the use

rights of the purchasers of the accommodations without the written

assent of not less than 51 percent of the time-share interest owners

other than the developer. This section shall not prevent the

developer from encumbering the purchaser's use rights so long as the

developer has sufficient protection as permitted by Section 11244.

11253. For single site time-share plans and component sites of

multisite time-share plans located in this state, the time-share

instrument shall require that the following insurance be at all times

maintained in force to protect time-share interest owners in the

time-share plan:

(a) Insurance against property damage as a result of fire and

other hazards commonly insured against, covering all real and

personal property comprising the time-share plan in an amount not

less than 80 percent of the full replacement value of the time-share

property.

(1) In a time-share use offering, the trustee shall be a named

coinsured, and if for any reason, title to the accommodation is not

held in trust, the association shall be named as a coinsured as the

agent for each of the time-share interest owners.

(2) In a time-share estate offering, the association shall be

named as a coinsured if it has title to the property or as a

coinsured as agent for each of the time-share interests owners if

title is held by the owners as tenants in common.

(3) If, after control of the governing body of the association has

passed to the owners other than the developer, and the association

amends the time-share instrument to reduce the percentage below 80

percent, the failure of the association to maintain coverage at 80

percent of replacement value shall not be grounds for denial of a

public report.

(b) Liability insurance against death, bodily injury, and property

damage arising out of or in connection with the use, ownership, or

maintenance of the accommodations of the time-share plan.

(1) The amounts of the insurance shall be determined by the

association, but shall not be less than five hundred thousand dollars

($500,000) to one million dollars ($1,000,000) for personal injury

and one hundred thousand dollars ($100,000) for property damage.

(2) The liability insurance policy shall provide for all of the

following:

(A) All time-share interest owners as a class are named as

additional insureds in a policy issued to the association.

(B) The waiver by the insurer of its right to subrogation under

the policy against any time-share interest owner or member of his or

her household.

(C) No act or omission by a time-share interest owner, unless

acting within the scope of his or her authority on behalf of the

association, shall void the policy or operate as a condition to

recovery under the policy by any other person.

11254. (a) In a time-share plan in which the fee or a long-term

leasehold interest in all or some of the accommodations and in

appurtenant real and personal property is to be transferred to the

association or to a corporate trustee under a trust agreement, the

conveyance shall be made prior to the closing of the escrow for the

first sale of a time-share interest in the accommodation.

(b) The developer may reserve easements in the real property

conveyed for purposes reasonably related to the conduct of commercial

activities in the time-share property, if the developer covenants to

use the easements in a manner that will minimize any adverse impact

on the use and enjoyment of the accommodation by any time-share

interest owner occupying it.

11255. (a) The department shall require that each of the

accommodations in a time-share plan offering time-share use interests

be conveyed to a trustee or an association acceptable to the

commissioner prior to the closing of the escrow for the first sale of

a time-share use interest that entitles the purchaser to occupy the

accommodation in question.

(b) If the accommodation in a time-share plan offering time-share

use interests that is free and clear of blanket encumbrances, other

than a lien of current real property taxes, is conveyed to a trustee

or an association, the trust or association instruments shall

include, but not be limited to, all of the following:

(1) Transfer of title to the accommodations to the trustee or

association.

(2) If the time-share use interests are conveyed to a trust, the

association as a party to the trust or an express third-party

beneficiary of the trust.

(3) Notice to the department of the intention of the trustee to

resign, if applicable.

(4) Continuance of the trustee in that capacity until a successor

trustee acceptable to the department assumes the position, if

applicable.

(5) Prohibition against any amendments of the trust or association

instruments adversely affecting the interests or rights of

time-share interest owners without the prior approval of the

association.

(6) Instructions for the distribution of condemnation or insurance

proceeds by the trustee or the association.

(c) The department may require that each of the accommodations in

a time-share plan offering time-share estate interests that is

subject to a blanket encumbrance be conveyed to a trustee acceptable

to the department prior to the closing of the escrow for the first

sale of a time-share estate which entitles the purchaser to occupy

the accommodation in question.

(d) If an accommodation in the time-share plan is conveyed to a

trustee pursuant to subdivision (c), the trust instrument shall

include all of the following provisions in addition to those set

forth in subdivision (b):

(1) The deposit into trust, and the retention for the duration of

the trust, of nondelinquent installment sales contracts or promissory

notes of time-share interests purchases having an aggregate

principal balance owing not ordinarily less than 150 percent of the

difference between the aggregate principal balance owing under

blanket encumbrances against the accommodation and the amount of

money, or its equivalent, in the trust and available at any time to

be applied to the reduction of the principal balance of the blanket

encumbrances.

(A) The trust instrument shall further provide that if the 150

percent requirement has not been met within six months after

execution of the trust instrument by the developer, the trustee shall

thereafter retain in the trust, or apply to debt service on the

blanket encumbrance, the entire amount of all installment payments

received on contracts or promissory notes until the 150 percent

requirement has been met.

(B) For purposes of this regulation, a contract or promissory note

is deemed delinquent when an installment payment is more than 60

days past due.

(C) If the developer for purposes of satisfying the requirements

of this subdivision proposes to deposit installment sales contracts

or promissory notes of obligor other than purchasers of interests in

the time-share plan into the trust, the developer shall have the

burden of establishing the liquidated value of the notes and

contracts to the satisfaction of the department.

(2) The deposit into trust, and the retention for the duration of

the trust, of funds in an amount at all times sufficient to pay the

total of three successive monthly installments of debt service on the

blanket encumbrance.

(A) If installments of debt service on a blanket encumbrance that

is fully amortized are due less frequently than monthly, the funds

retained in the trust shall be sufficient to pay all installments

becoming due within the next succeeding six months, or, if no

installments are due within the next succeeding six months the next

installment due.

(B) If a blanket encumbrance against the trust property is an

interest-only loan, contains a balloon payment provision, or is

otherwise not fully amortized under the terms for repayment, the

trust instrument shall require that the developer make monthly

payments into the trust sufficient to pay debt service installments

as they become due and to create a sinking fund to extinguish the

debt at its maturity.

(3) Payment by the trustee of debt service on the blanket

encumbrance, property taxes, or assessments on insurance premiums,

either as the entity having primary responsibilities for the payments

or the entity secondarily responsible if the person with primary

responsibility fails to make the payments in a timely manner.

(4) The deposit or investment by the trustee of funds constituting

a part of the trust corpus in interest bearing accounts, treasury

bills, certificates of deposit, or similar investments.

(e) In the case of a time-share plan offering time-share use

interests that have been conveyed to a trustee, the trust for the

accommodation shall be irrevocable during the time that any

time-share interest owner has a right to the occupancy of an

accommodation.

(f) In the case of a time-share plan offering time-share use

interests that have been conveyed to an association, the association

shall not be dissolved or terminated during the time that any

time-share interest owner has the right to occupancy of an

accommodation.

(g) In a time-share plan offering time-share estate interests, the

trust for an accommodation shall be irrevocable until the

extinguishment of all blanket monetary encumbrances against the

accommodation.

11256. (a) The contract proposed to be used by a developer

applying for a public report for the sale or lease of time-share

interests shall provide that if the escrow for sale or lease of a

time-share interest does not close on or before the date set forth in

the contract, or a later closing date mutually agreed to by the

developer and the prospective purchaser or lessee, within 15 days

after the closing date set forth in the contract or an extended

closing date mutually agreed to by the developer and the prospective

purchaser or lessee, the developer shall, except as provided in

subdivisions (c) to (h), inclusive, order all of the money remitted

by the prospective purchaser or lessee under the terms of the

contract for acquisition of the time-share interest (purchase money)

to be refunded to the prospective purchaser or lessee. Any extension

of the closing of escrow shall be in writing and shall clearly and

conspicuously disclose that the purchaser is not obligated to extend

the closing of escrow.

(b) The contract may provide for disbursements or charges to be

made against purchase money for payments to third parties for credit

reports, escrow services, preliminary title reports, appraisals, and

loan processing services by the parties if the contract includes the

following:

(1) Specific enumeration of all of the disbursements or charges

that may be made against purchase money.

(2) The developer's estimate of the total amount of the

disbursements and charges.

(c) Any contractual provision that calls for disbursement or a

charge against purchase money based upon the prospective purchaser's

or lessee's alleged failure to complete the purchase of the

time-share interest shall conform with Sections 1675, 1676, 1677, and

1678 of the Civil Code.

(d) Except for a disbursement made following substantial

compliance with the procedures set forth in subdivision (f) or

pursuant to a written agreement of the parties that either cancels

the contract or is executed after the final closing date specified by

the parties, a disbursement or charge against purchase money as

liquidated damages may be done only pursuant to a determination by a

court of law, or by an arbitrator if the parties have so provided by

contract, that the developer is entitled to a disbursement or charge

against purchase money as liquidated damages.

(e) A contractual provision for a determination by arbitration

that the developer is entitled to a disbursement or charge against

purchase money as liquidated damages shall

require that the arbitration be conducted in

accordance with procedures that are equivalent in substance to the

Commercial Arbitration Rules of the American Arbitration Association,

that any arbitration include every cause of action that has arisen

between the prospective purchaser or lessee and the developer under

the contract, and that the developer remit the fee to initiate

arbitration with the costs of the arbitration ultimately to be borne

as determined by the arbitrator.

(f) The contract of sale may include a procedure under which

purchase money may be disbursed by the escrowholder to the developer

as liquidated damages upon the prospective purchaser's or lessee's

failure to timely give the escrowholder the prospective purchaser's

or lessee's written objection to disbursement of purchase money as

liquidated damages. This procedure shall contain at least the

following elements:

(1) The developer shall give written notice, in the manner

prescribed by Section 116.340 of the Code of Civil Procedure for

service in a small claims action, to the escrowholder and to the

prospective purchaser or lessee that the prospective purchaser or

lessee is in default under the contract that the developer is

demanding that the escrowholder remit _____ dollars ($____) from the

purchase money to the developer as liquidated damages unless, within

20 days, the prospective purchaser or lessee gives the escrowholder

the prospective purchaser's or lessee's written objection to the

disbursement of purchase money as liquidated damages.

(2) The prospective purchaser or lessee shall have a period of 20

days from the date of receipt of the developer's 20-day notice and

demand in which to give the escrowholder the prospective purchaser or

lessee written objection to the disbursement of purchase money as

liquidated damages.

(g) The contract may not make the prospective purchaser's or

lessee's failure to timely give the escrowholder the aforesaid

written objection a waiver of any cause of action the prospective

purchaser or lessee may have against the developer under the contract

unless the waiver is conditioned upon service of the developer's

20-day notice and demand in a manner prescribed by Section 116.340 of

the Code of Civil Procedure for service in a small claims action.

(h) If the developer has had the use of purchase money pending

consummation of the sale or lease transaction under authorization by

the department pursuant to Section 11243, the developer shall

immediately upon alleging the default of the prospective purchaser or

lessee, transmit to the escrowholder, funds equal to all of the

purchase money paid by the prospective purchaser or lessee.

 

Article 4. Management and Governance

 

11265. (a) For single site time-share plans and component sites

of a specific time-share interest multisite time-share plan, the

following requirements apply:

(1) Except as provided in paragraph (2), regular assessments to

defray the expenses of maintaining the time-share property and

operating the time-share plan shall be levied against each time-share

interest owner according to the ratio that the number of time-share

interests owned by a time-share interest owner assessed bears to the

total number of time-share interests subject to assessments. Regular

assessments levied by the association shall not exceed the amount

necessary to defray the estimated expenses for which the assessments

are levied.

(2) The assessment against each owner in the time-share plan may

be determined according to a formula or schedule under which

assessments against each time-share interest owner are equitably

apportioned in accordance with operational and maintenance costs

attributable to each time-share interest owner.

(3) A special assessment shall be levied upon the same basis as

that prescribed for the levying of regular assessments except in the

case where the special assessment is levied against a time-share

interest owner for the purpose of reimbursing the association for

costs incurred in bringing the time-share interest owner into

compliance with provisions of the governing instruments for the

time-share plan.

(4) All time-share interests in the time-share plan for which a

public report has been issued including those time-share interests

held by the developer of the time-share plan are interests subject to

the payment of regular and special assessments.

(5) The governing body of the association may be authorized by the

governing instruments to impose, without the vote or written assent

of the association, a regular annual assessment per time-share

interest that is as much as 20 percent greater than the regular

annual assessment for the immediately preceding fiscal year. An

annual assessment for each time-share interest that is more than 20

percent greater than the regular assessment per time-share interest

for the immediately preceding fiscal year may not be levied without

the vote or written assent of a majority of the voting power of the

association residing in members other than the developer. An

increase in the annual assessment attributable to an increase in real

property taxes against accommodations of the time-share property

shall be excluded in determining whether the annual assessment is

more than 20 percent greater than the regular assessment per interest

for the preceding fiscal year.

(6) Except as provided in this section, special assessments

against time-share interest owners in a time-share plan may not be

imposed without the vote or written assent of a majority of the

voting power of the association residing in members other than the

developer. The governing body of the association may be authorized

by the governing instruments to impose special assessments without

the vote or written assent of the association as follows:

(A) Special assessments against all time-share interest owners in

the time-share plan, other than a special assessment to restore or

rebuild because of damage or destruction to an accommodation, which

in the aggregate in any fiscal year do not exceed 5 percent of the

budgeted gross expenses of the association for that fiscal year.

(B) A special assessment for the repair or rebuilding of an

accommodation that does not exceed 10 percent of the budgeted gross

expenses of the association for the fiscal year in which the

assessment is levied.

(C) Special assessments against a time-share interest owner or

owners for the purpose of reimbursing the association for costs

incurred in bringing the time-share interest owner into compliance

with provisions of the governing instruments for the time-share plan.

 

(7) Regular assessments against all of the time-share interests in

an accommodation of the time-share plan shall commence on the same

date. Regular assessments shall commence on the first day of the

month following the closing of the escrow of the first sale of a

time-share interest in the time-share plan, but may be delayed to the

date of commencement of time-share interest owners' occupancy rights

in the accommodation or to a date that is not more than six months

later than the date of closing of the first sale involving a right to

use the accommodation, whichever occurs earlier in time.

(b) For single site time-share plans and component sites of a

multisite time-share plan located outside of the state the time-share

instruments shall include the subject matter set forth in paragraphs

(1) to (4), inclusive, of subdivision (a). The time-share

instruments shall be in compliance with the applicable laws of the

state or jurisdiction in which the time-share property or component

site is located, and if a conflict exists between the affirmative

standards of the laws of the situs state and the requirements set

forth in this section, the law of the situs state shall control. If

the time-share instruments provide for the matters contained in

paragraphs (1) to (4), inclusive, of subdivision (a), the time-share

instruments shall be deemed to be in compliance with the requirements

of paragraphs (1) to (4), inclusive, of subdivision (a) and this

subdivision and the developer shall not be required to make revisions

in order to comply with paragraphs (1) to (4), inclusive, of

subdivision (a) and this subdivision. If the maximum increase in

annual assessments for a time-share plan located outside of this

state is greater than the 20 percent set forth in paragraph (5) of

subdivision (a), the public report shall include the following

disclosure in conspicuous 14-point type:

YOUR ANNUAL ASSESSMENTS ARE NOT SUBJECT TO THE CALIFORNIA LIMITATION

OF A 20% ANNUAL INCREASE WITHOUT THE VOTE OF THE OWNERS OTHER THAN

THE DEVELOPER. YOUR ASSESSMENT MAY BE INCREASED BY AS MUCH AS ____%

PER YEAR.

 

(c) For nonspecific time-share interest multisite time-share plans

the following requirements apply:

(1) Except as provided in paragraph (2), regular assessments to

defray the expenses of maintaining and operating the multisite

time-share plan shall be levied against each time-share interest

owner according to the ratio that the number of time-share interests

owned by a time-share interest owner assessed bears to the total

number of time-share interests subject to assessments.

(2) The assessment against each time-share interest owner in the

multisite time-share plan may be determined according to a formula or

schedule under which assessments against each time-share interest

owner are equitably apportioned in accordance with operational and

maintenance costs attributable to each time-share interest owner.

(3) A special assessment shall be levied upon the same basis as

that prescribed for the levying of regular assessments except in the

case where the special assessment is levied against a time-share

interest owner for the purpose of reimbursing the association for

costs incurred in bringing the time-share interest owner into

compliance with provisions of the governing instruments for the

time-share plan.

(4) All time-share interests in the multisite time-share plan for

which a public report has been issued including those time-share

interests held by the developer of the multisite time-share plan are

interests subject to the payment of regular and special assessments.

 

11266. (a) An amendment of a provision of the declaration or

other document establishing the time-share plan may not be adopted

without the vote or written assent of at least 25 percent of the

voting power of the association residing in members other than the

developer.

(b) An amendment of the articles of incorporation or association

may not be enacted without the vote or written assent of at least 25

percent of the governing body and 25 percent of the voting power of

the association residing in members other than the developer.

(c) An amendment of the bylaws of the association may not be

enacted without the vote or written assent of at least 10 percent of

the voting power of the association residing in members other than

the developer.

(d) An amendment to the rules and regulations of the association

may not be enacted without the vote or written assent of at least a

majority of the governing body of the association.

(e) The percentage of the voting power necessary to amend a

specific clause or provision in the time-share instrument, articles,

or bylaws shall not be less than the prescribed percentage of

affirmative votes or written assents required for action to be taken

under that clause.

(f) In addition to the restrictions upon the enactment of

amendments of the governing instruments set forth in this section,

the governing instruments may include provisions consistent with

subdivision (c) of Section 11269 whereby the vote of the developer

must be given effect in the amendatory process.

(g) For a single site time-share plan or a component site of a

specific time-share interest time-share plan or a nonspecific

time-share interest multisite time-share plan located outside this

state, that is being offered in this state, the public report shall

include the following disclosure in conspicuous 14-point type:

THE DECLARATION OR OTHER DOCUMENT ESTABLISHING THIS TIME-SHARE PLAN

MAY BE AMENDED BY A VOTE OF ____% OF THE MEMBERS OF THE ASSOCIATION.

THE BYLAWS OF THE ASSOCIATION MAY BE AMENDED BY A VOTE OF ____% OF

THE MEMBERS.

 

11267. (a) The time-share instruments shall require the

employment of a managing entity for the time-share plan or component

site pursuant to a written management agreement that shall include

all of the following provisions:

(1) Delegation of authority to the managing entity to carry out

the duties and obligations of the association or the developer to the

time-share interest owners.

(2) Authority of the managing entity to employ subagents, if

applicable.

(3) A term of not more than five years with automatic renewals for

successive three-year periods after expiration of the first term

unless the association by the vote or written assent of a majority of

the voting power residing in members other than the developer

determines not to renew the contract and gives appropriate notice of

that determination. However, in those time-share plans where the

association is controlled by owners other than the developer, the

management agreement shall not be subject to the term limitations set

forth in this section, and any longer term shall not be grounds for

denial of a public report, unless the longer term of the management

contract is the result of the developer exercising control.

(4) Termination for cause at any time by the governing body of the

association. If the single site time-share plan or the component

site of a multisite time-share plan is located within the state, then

that termination provision shall include a provision for arbitration

in accordance with the Commercial Arbitration Rules of the American

Arbitration Association if requested by or on behalf of the managing

entity.

(5) Not less than 90 days' written notice to the association of

the intention of the managing entity to resign.

(6) Enumeration of the powers and duties of the managing entity in

the operation of time-share plan and the maintenance of the

accommodations comprising the time-share plan.

(7) Compensation to be paid to the managing entity.

(8) Records to be maintained by the managing entity.

(9) A requirement that the managing entity provide a policy for

fidelity insurance or bond for the activities of the managing entity,

payable to the association, in the sum of the largest amount of

funds expected to be held or controlled by the managing entity at any

time during the year, pursuant to the budget.

(10) Errors and omissions insurance coverage for the managing

entity, if available.

(11) Delineation of the authority of the managing entity and

persons authorized by the managing entity to enter into

accommodations of the time-share plan for the purpose of cleaning,

maid service, maintenance and repair including emergency repairs, and

for the purpose of abating a nuisance or dangerous, unlawful, or

prohibited activity being conducted in the accommodation.

(12) Description of the duties of the managing entity, including,

but not limited to, the following:

(A) Collection of all assessments as provided in the time-share

instruments.

(B) Maintenance of all books and records concerning the time-share

plan.

(C) Scheduling occupancy of accommodations, when purchasers are

not entitled to use specific time-share periods, so that all

purchasers will be provided the opportunity for use and possession of

the accommodations of the time-share plan, that they have purchased.

 

(D) Providing for the annual meeting of the association of owners.

 

(E) Performing any other functions and duties related to the

maintenance of the accommodations or that are required by the

time-share instrument.

(b) Any written management agreement in existence as of the

effective date of this chapter shall not be subject to the term

limitations set forth above.

(c) For single site time-share plans and component sites of a

multisite time-share plan located outside of the state, the

time-share instruments shall include the subject matter set forth in

subdivision (a). The time-share instruments shall be in compliance

with the applicable laws of the state or jurisdiction in which the

time-share property or component site is located, and if a conflict

exists between laws of the situs state and the requirements set forth

in this section, the law of the situs state shall control. If the

time-share instruments provide for the matters contained in

subdivision (a), the time-share instruments shall be deemed to be in

compliance with the requirements of subdivision (a) and the developer

shall not be required to make revisions in order to comply with

subdivision (a) and this subdivision.

11268. (a) Unless impracticable because of the number of members

of the association, their places of residence in relation to each

other, the international nature of the offering, or other factors,

provision shall be made for regular meetings of members of the

association of time-share interest owners. Ordinarily regular

meetings of members shall be scheduled not less frequently than once

each calendar year at a time and place to be fixed by the bylaws or

by resolution of the governing body. The first meeting of the

association shall be scheduled not later than one year after the

closing of the escrow for the first sale of a time-share interest in

the time-share plan or completion of construction, whichever shall

first occur.

(b) Provision shall be made for special meetings of the

association to be promptly called by the governing body upon either

of the following:

(1) The vote of a majority of the governing body.

(2) Receipt of a written request signed by members representing at

least 5 percent of the voting power of the association residing in

members other than the developer.

(c) Meetings of the association shall be held at a suitable

location that is readily accessible at reasonable cost to the largest

possible number of members.

(d) Written notice of regular and special meetings shall be given

to members by first-class mail. This notice shall be given not less

than 14 days and not more than 90 days before the scheduled date of

the meeting. The notice, whether for a regular or special meeting

shall specify the place, day, and hour of the meeting and a brief

statement of the matters which the governing body intends to present,

or believes that others will present, for action by the members.

(e) (1) The bylaws of the association shall establish the quorum

for a meeting of members at not less than 5 percent nor more than

331/3 percent, of the voting power of the association residing in

members other than the developer, represented in person or by proxy.

 

(2) In the absence of a quorum as prescribed by the bylaws, no

business shall be conducted and the presiding officer shall adjourn

the meeting sine die.

(3) If less than one-third of the total voting power of the

association is in attendance, in person or by proxy, at a regular or

special meeting of the association, only those matters of business,

the general nature of which was given in the notice of the meeting

may be voted upon by the members.

(f) Any action that may be taken at any regular or special meeting

of members may be taken without a meeting if the following

requirements are met:

(1) A written ballot is distributed to every member entitled to

vote setting forth the proposed action, providing an opportunity to

signify approval or disapproval of the proposal, and providing a

reasonable time for the members to return the ballot to the

association.

(2) The number of votes cast by ballot within the specified time

period equals or exceeds the quorum required to be present at a

meeting authorizing the action.

(3) The number of approvals of the action equals or exceeds the

number of votes required to approve the action at a meeting at which

the total number of votes cast was the same as the number of votes

cast by written ballot.

(4) The written ballot distributed to members of the association

affords an opportunity for the member to specify a choice between

approval and disapproval of each order of business proposed to be

acted upon by the association and further provides that the vote of

the members shall be cast in accordance with the choice specified.

(g) The bylaws of the association may provide that governing body

members may be elected by written ballot.

(h) A form of proxy may be distributed to each member to afford

him or her the opportunity to vote in absentia at a meeting of

members of the association provided that it meets the requirements

for a written ballot set forth in paragraph (4) of subdivision (f)

and includes the name or names of members who expect to be in

attendance in person at the meeting to whom the proxy is to be given

for the purpose of casting the vote to reflect the absent member's

vote as specified in the form of proxy.

11269. (a) A member of an association including associations that

provide for unequal assessments against members, shall be entitled

to one vote for each time-share interest owned.

(b) An association may have two classes of members for voting

purposes according to the following provisions:

(1) Each time-share interest owner other than the developer of the

time-share plan shall be a class A member. If a time-share interest

is owned by more than one person, each time-share interest owner

shall be a class A member, but only one vote may be cast for each

interest.

(2) The developer shall be the class B member and shall have one

vote for each time-share interest owned by him or her which has been

authorized to be offered for sale by the issuance of a public report.

 

(3) Class B membership shall be automatically converted to class A

membership, and class B membership shall thereafter cease to exist,

when the total outstanding votes held by the class B member falls

below 20 percent of the total voting power of the association.

(c) Except as otherwise expressly provided, no regulation which

requires the approval of a prescribed percentage of the voting power

residing in members other than the developer or a prescribed

percentage of the voting power of class A members, for action to be

taken by the association, is intended to preclude the developers from

casting votes attributable to the time-share interests which he or

she owns. Governing instruments may specify the following with

respect to approval of action by the membership of the association

other than an action to enforce an obligation of the developer:

(1) In those associations in which class A and class B memberships

exist, the vote or written assent of a prescribed percentage of the

class A voting power and the vote or written assent of the class B

member.

(2) In those associations in which a single class of voting

membership exists, either as originally established or after the

conversion of the class B membership to class A memberships, the vote

or written assent of a prescribed percentage of the total voting

power of the association and the vote or written assent of a

prescribed percentage of the voting power of members other than the

developer.

11270. (a) The governing body shall consist of three directors

for an association that does not contemplate more than 100 members

and either five or seven directors for an association that

contemplates more than 100 members.

(b) (1) The first governing body shall consist of directors

appointed by the developer. These directors shall serve until the

first meeting of the association at which time an election of all of

the directors for the association shall be conducted.

(2) A special procedure shall be established by the governing

instruments to assure that at the first election of the governing

body, and at all times thereafter, at least one of the incumbent

directors has been elected solely by the votes of members other than

the developer.

(3) A director who has been elected to office solely by the votes

of the members of the association other than the developer may be

removed from the governing body prior to the expiration of his or her

term of office only by a vote of a prescribed percentage of the

voting power residing in members other than the developer.

(c) The terms of office of governing body members may be staggered

provided that no person may serve a term of more than three years

without standing for reelection.

(d) For board of director members serving at the appointment of

the developer, the developer may change the designated board member

without the need of any further consent by the association. However,

the term of the applicable director's seat on the governing body

shall not be affected by that change.

11271. (a) Regular meetings of the governing body of the

association shall be held as prescribed in the bylaws, but not less

frequently than annually.

(b) (1) Regular and special meetings of the governing body shall

be held in or near the location of the time-share plan unless a

meeting at another location would significantly reduce the cost to

the association or the inconvenience to directors.

(2) If the time and place of the regular meeting of the governing

body is not fixed by the governing instruments, notice of the time

and place of meeting shall be communicated in writing, including by

facsimile, electronic mail, or other form of written or electronic

communication, to directors not less than 14 days prior to the

meeting. However, that notice of a meeting is not required to be

given to any governing body member who has signed a waiver of notice

or a written consent to the holding of the meeting.

(c) (1) A special meeting of the governing body may be called by

written notice signed by any two members of the governing body.

(2) The notice of a special meeting shall specify the time and

place of the meeting and the nature of any special business to be

considered.

(3) Notice of a special meeting shall be communicated in writing,

including by facsimile, electronic mail, or other form of written or

electronic communication, to directors not less than 14 days prior to

the meeting. However, notice of the meeting is not required to be

given to any governing body member who signed a waiver of notice or a

written consent to the holding of the meeting.

(d) (1) Regular and special meetings of the governing body shall

be open to all members of the association provided that members who

are not on the governing body may not participate in any

deliberations or discussions unless expressly so authorized

by the governing body.

(2) The governing body may, with the approval of a majority of a

quorum of its members, adjourn a meeting and reconvene in executive

session to discuss and vote upon personnel matters, litigation in

which the association is or may become involved, and orders of

business of a similar nature. The nature of any and all business to

be considered in executive session shall first be announced in open

session.

(e) A bare majority of the total members of authorized members of

the governing body shall constitute a quorum for the conduct of

business.

(f) The governing instruments for the time-share plan shall

provide for reimbursement by the association for transportation

expenses incurred and reasonable per diem payments to governing body

members for attendance at regular and special meetings of the

governing body.

11272. (a) The following information concerning the time-share

plan shall be made available to all time-share interest owners in the

time-share plan:

(1) A proposed budget for each fiscal year consisting of the

information required by Section 11240 shall be distributed not less

than 15 days prior to the beginning of the fiscal year to which the

budget applies.

(2) An audit of the financial statements of the association by an

independent certified public accountant shall be performed each year

and shall be made available upon request by a time-share owner 120

days after the close of the fiscal year. The audited financial

statements shall be included in a report that includes all of the

following:

(A) A balance sheet as of the end of the fiscal year.

(B) An operating (income) statement for the fiscal year.

(C) A statement of the net changes in the financial position of

the time-share plan during the fiscal year.

(D) For any fiscal year in which the gross income to the

association exceeds seventy-five thousand dollars ($75,000), a copy

of the review of the annual report prepared in accordance with

generally accepted accounting principles.

(E) A list of the names and methods of contacting the members of

the governing body of the association.

(3) A list of the orders of business to be considered at the

annual meeting of members of the association shall be distributed not

less than 14 days prior to the meeting date. This list shall

include the name, address, and a brief biographical sketch if

available of each member of the association who is a candidate for

election to the governing body.

(b) In lieu of the distribution of the budget and report required

by subdivision (a), the governing body may elect to distribute a

summary of the budget and report to all time-share interest owners

along with a written notice that the budget and report is available

at the business office of the association or at another suitable

location within the boundaries of the development, and that copies

will be provided upon request and at the expense of the association.

If any time-share interest owner requests that a copy of the budget

and report required by subdivision (a) be provided to the time-share

interest owner, the association shall provide the copy to the

time-share interest owner by facsimile, electronic mail, or

first-class United States mail at the expense of the association and

delivered within 10 days. The written notice that is distributed to

each of the time-share interest owners shall be in conspicuous

14-point type on the front page of the summary of the budget and

report.

(c) Delivery of the information specified in subdivision (a) may

be combined where appropriate.

(d) For single site time-share plans and component sites of a

multisite time-share plan located outside of the state, the

association shall be subject to the provisions set forth in this

section. The association must be in compliance with the applicable

laws of the state or jurisdiction in which the time-share property or

component site is located, and if a conflict exists between laws of

the situs state and the requirements set forth in this section, the

law of the situs state shall control. If the association provides

for the dissemination of information provided for in this section,

the association shall be deemed to be in compliance with the

requirements of this section and neither the developer nor the

association shall be required to make revisions to the time-share

instruments or budget in order to comply with this section.

11273. (a) The books of account, minutes of members and governing

body meetings, and all other records of the time-share plan

maintained by the association or the managing entity shall be made

available for inspection and copying by any member, or by his or her

duly appointed representative, at any reasonable time for a purpose

reasonably related to membership in the association.

(b) The records shall be made available for inspection at the

office where the records are maintained. Upon receipt of an

authenticated written request from a member along with the fee

prescribed by the governing body to defray the costs of reproduction,

the managing entity or other custodian of records of the association

or the time-share plan shall prepare and transmit to the member a

copy of any and all records requested.

(c) The governing body shall establish reasonable rules with

respect to all of the following:

(1) Notice to be given to the managing entity or other custodian

of the records by the member desiring to make the inspection or to

obtain copies.

(2) Hours and days of the week when a personal inspection of the

records may be made.

(3) Payment of the cost of reproducing copies of records requested

by a member.

(d) Every governing body member shall have the absolute right at

any time to inspect all books, records, and documents of the

association and all real and personal properties owned and controlled

by the association.

(e) The association shall maintain among its records a complete

list of the names and addresses of all owners of time-share interests

in the time-share plan. The association shall update this list no

less frequently than every six months. Unless otherwise provided in

the time-share instruments, the association may not publish this

owner's list or provide a copy of it to any time-share interest owner

or to any third party or use or sell the list for commercial

purposes.

(f) For single site time-share plans and component sites of a

multisite time-share plan located outside of the state, the

association shall be subject to the provisions set forth in this

section. The association must be in compliance with the applicable

laws of the state or jurisdiction in which the time-share property or

component site is located, and if a conflict exists between laws of

the situs state and the requirements set forth in this section, the

law of the situs state shall control. If the association and the

time-share instruments provide for the matters contained in this

section, the association shall be deemed to be in compliance with the

requirements of this section and neither the developer nor the

association shall be required to make revisions to the time-share

instruments in order to comply with the section.

11274. (a) The association shall not be authorized to cause the

absolute forfeiture of a time-share interest owner's right, title, or

interest in the time-share plan on account of the time-share

interest owner's failure to comply with provisions of the time-share

instrument or the rules and regulations for the time-share plan

except pursuant to either of the following:

(1) The judgment of a court or the decision of an arbitrator as

provided in the time-share instrument.

(2) A foreclosure or sale under a power of sale for the failure of

a time-share interest owner to pay assessments duly levied by the

association.

(b) The time-share instrument may authorize the governing body of

the association, or the managing entity acting on behalf of the

governing body, to suspend a time-share interest owner's right to the

occupancy of an accommodation, and all related rights and privileges

as a time-share interest owner of a time-share interest in the

time-share plan, during the period of time that the time-share

interest owner is delinquent in the payment of regular or special

assessments or other charges duly levied by the association. The

time-share interest owner shall be given written notice of the

suspension of his or her rights and privileges immediately after the

decision to suspend has been made.

(c) The time-share instrument may authorize the association to

impose a monetary penalty to suspend a time-share interest owner's

right to use an accommodation or other facility that is part of the

time-share plan or to take other disciplinary action that is

appropriate, short of the forfeiture of the time-share interest owner'

s right, title, and interest in the time-share plan, for violations

of the provisions of the time-share instrument and of the rules and

regulations for operation of the time-share plan by the time-share

interest owner, his or her guests or persons under his or her

control, including, but not limited to, all of the following:

(1) Failure to vacate an accommodation upon expiration of the

time-share interest owner's use period.

(2) Damage to an accommodation or any other real or personal

property that is part of the time-share plan.

(3) Permitting a time-share interest to be subject to a lien,

other than the lien of nondelinquent real property taxes or

assessments, claim, or charge that could result in the sale of

time-share interests of other time-share interest owners.

(4) Creating a disturbance that interferes with the use and

enjoyment of facilities of the time-share plan by other time-share

interest owners.

(d) Before disciplinary action authorized under subdivision (c)

can be imposed by the association, the time-share interest owner

against whom the action is proposed to be taken shall be given

30-days prior written notice and the opportunity to present a written

or oral defense to the charges.

(1) The governing body of the association shall decide whether the

time-share interest owner's defense shall be oral or written.

(2) The time-share interest owner shall be notified of the

decision of the governing body of the association before disciplinary

action is taken.

(e) The association may delegate to the managing entity, the power

and authority to carry out disciplinary actions duly imposed by the

governing body.

(f) For single site time-share plans and component sites of

specific time-share interest multisite time-share plans and

nonspecific time-share interest multisite time-share plans located

outside this state, and offered for sale in this state, the public

report shall contain the following disclosure in conspicuous 14-point

type:

THIS TIME SHARE PLAN MAY NOT BE SUBJECT TO THE SAME PROTECTIONS

AGAINST FORFEITURE AND FORECLOSURE AS PROVIDED BY CALIFORNIA LAW.

YOU SHOULD BECOME FAMILIAR WITH THE PROCEDURES PROVIDED BY THE LAWS

OF THE STATE IN WHICH THE TIME-SHARE PLAN IS LOCATED.

 

11275. (a) Any contractual provision or other provision in the

time-share instruments setting forth terms, conditions, and

procedures for resolution of a dispute or claim between a time-share

interest owner and a developer, or any provision in the time-share

instruments setting forth terms, conditions, and procedures for

resolution of a dispute of a claim between an association and the

developer, shall, at a minimum, provide that the dispute or claim

resolution process, proceeding, hearing, or trial be conducted in

accordance with the following rules:

(1) For the developer to advance the fees necessary to initiate

the dispute or claim resolution process, with the costs and fees,

including ongoing costs and fees, if any, to be paid as agreed by the

parties and if they cannot agree then the costs and fees are to be

paid as determined by the person or persons presiding at the dispute

or claim resolution proceeding or hearing.

(2) For a neutral or impartial person to administer and preside

over the claim or dispute resolution process.

(3) For the appointment or selection, as designation, or

assignment of the person to administer and preside over the claim or

dispute resolution process within a specific period of time, which in

no event shall be more than 60 days from initiation of the claim or

dispute resolution process or hearing. The person appointed,

selected, designated, or assigned to preside may be challenged for

bias.

(4) For the venue of the claim or dispute resolution process to be

in the county where the time-share is located unless the parties

agree to some other location.

(5) For the prompt and timely commencement of the claim or dispute

resolution process. When the contract provisions provide for a

specific type of claim or dispute resolution process, the process

shall be deemed to be promptly and timely commenced if it is to be

commenced in accordance with the rules applicable to that process.

If the rules do not specify a date by which the proceeding or hearing

is required to commence, then commencement shall be by a date agreed

upon by the parties, and if they cannot agree, a date shall be

determined by the person presiding over the dispute resolution

process.

(6) For the claim or dispute resolution process to be conducted in

accordance with rules and procedures that are reasonable and fair to

the parties.

(7) For the prompt and timely conclusion of the claim or dispute

resolution process, including the issuance of any decision or ruling

following the proceeding or hearing.

(8) For the person presiding at the claim or dispute resolution

process to be authorized to provide all recognized remedies available

in law or equity for any cause of action that is the basis of the

proceeding or hearing. The parties may authorize the limitation or

prohibition of punitive damages.

(b) A copy of the rules applicable to the claim or dispute

resolution process shall be submitted as part of the application for

a public report.

(c) If the claim or dispute resolution process provides or allows

for a judicial remedy in accordance with the laws of this state, it

shall be presumed that the proceeding or hearing satisfies the

provisions of subdivision (a).

 

Article 5. Powers, Investigation, and Enforcement

 

11280. (a) Except as specifically provided in this section, the

regulation of time-share plans and exchange programs is an exclusive

power and function of the state. A unit of local government may not

regulate time-share plans or exchange programs.

(b) Notwithstanding subdivision (a), no provision of this chapter

invalidates or modifies any provision of any zoning, subdivision, or

building code or other real estate use law, ordinance, or regulation.

 

11281. The commissioner may adopt, repeal, or amend forms and

regulations that are necessary to effectuate the intent of the

Legislature in carrying out this chapter. These forms and

regulations and any order, permit, decision, demand, or requirement

issued by the commissioner shall be in writing and adopted pursuant

to the Administrative Procedure Act (Chapter 3.5 (commencing with

Section 11340) of Part 1 of Division 3 of Title 2 of the Government

Code).

11282. The commissioner may investigate the actions or

qualifications of any person or persons holding or claiming to hold a

public report under this chapter.

11283. (a) Whenever the commissioner determines from available

evidence that a person has done any of the following, the

commissioner may order the person to desist and refrain from those

acts and omissions or from the further sale or lease of interests in

the time-share plan until the condition has been corrected:

(1) The person has violated or caused the violation of any

provision of this chapter or the regulations pertaining thereto.

(2) The person has violated or caused a violation of Section

17537, 17537.1, 17537.2, or 17539.1, in advertising or promoting the

sale of time-share interests.

(3) The person has failed to fulfill representations or assurances

with respect to the time-share plan or the time-share offering upon

which the department relied in issuing a public report.

(4) The person has failed to inform the department of material

changes that have occurred in the time-share or time-share offering

that have caused the public report to be misleading or inaccurate or

which would have caused the department to deny a public report if the

conditions had existed at the time of issuance.

(b) Upon receipt of such an order, the person or persons to whom

the order is directed shall immediately discontinue activities in

accordance with the terms of the order.

(c) Any person to whom the order is directed may, within 30 days

after service thereof upon him or her, file with the commissioner a

written request for hearing to contest the order. The commissioner

shall, after receipt of a request for hearing, assign the matter to

the Office of Administrative Hearings to conduct a hearing for

findings of fact and determinations of the issues set forth in the

order. If the hearing is not commenced within 15 days after receipt

of the request for hearing, or on the date to which continued with

the agreement of the person requesting the hearing, or if the

decision of the commissioner is not rendered within 30 days after

completion of the hearing, the order shall be deemed to be vacated.

(d) Service and proof of service of an order issued by the

commissioner pursuant to this section may be made in a manner and

upon those persons as prescribed for the service of summons in

Article 3 (commencing with Section 415.10), Article 4 (commencing

with Section 416.10), and Article 5 (commencing with Section 417.10)

of Chapter 4 of Title 5 of Part 2 of the Code of Civil Procedure.

11284. Notwithstanding any other provisions of this chapter or of

the Administrative Procedure Act (Chapter 3.5 (commencing with

Section 11340) of Part 1 of Division 3 of Title 2 of the Government

Code), the commissioner may negotiate agreements with registrants and

applicants resulting in disciplinary consent orders. The consent

order may provide for any form of discipline provided for in this

chapter. The consent order shall provide that it is not entered into

as a result of any coercion by the commissioner. The consent order

shall be accepted by signature or rejected by the commissioner in a

timely manner.

11285. An action for damages or for injunctive or declaratory

relief for a violation of this chapter may be brought by any

time-share interest owner or association against the developer,

seller, or marketer of time-share interests, an escrow agent, or the

managing entity. Relief under this section does not exclude other

remedies provided by law.

11286. (a) It shall be unlawful for any person to make, issue,

publish, deliver, or transfer as true and genuine any public report

that is forged, altered, false, or counterfeit, knowing it to be

forged, altered, false, or counterfeit or to cause to be made or

participate in the making, issuance, delivery, transfer, or

publication of a public report with knowledge that it is forged,

altered, false, or counterfeit.

(b) Any person who violates subdivision (a) is guilty of a public

offense punishable by a fine not exceeding ten thousand dollars

($10,000), by imprisonment in the state prison, by imprisonment in

the county jail not exceeding one year, or by both the fine and

imprisonment.

(c) The penalty provided by this section is not an exclusive

penalty, and does not affect any other penalty, relief, or remedy

provided by law.

11287. Any person who violates Section 11226, 11227, 11234,

11244, 11245, or 11283, is guilty of a public offense punishable by a

fine not to exceed ten thousand dollars ($10,000), by imprisonment

in the state prison or in a county jail not exceeding one year, or by

both the fine and imprisonment.

11288. This chapter shall take effect on July 1, 2005.